HomeMy WebLinkAbout07 276 1582679 Ontario Inc (Lakefield Estates) Subdivision Agreement
.
.
.
.
TIlE CORPORATION OF THE MUNICIPALITY (If KINCARDINE
BY-LAW
No. 2007 - 276
BEING A BY.LAW TO AUTHORIZE THE EXECUTION OF A SUBDIVISION
AGREEMENT WITH 1582679 ONTARIO INC. CONCERNING PART OF LOTS
A, B AND C, CONCESSION A, [GEOGRAPHIC TOWNSHIP OF KINCARDINE)
MUNICIPALITY OF KINCARDINE
(Lakefield Estates Subdivision)
WHEREAS Section 51 (26) of the Planning Act 1990, Chapter 13 authorizes
municipalitIes to enter into subdivision agreements as a condition to the approval
ofa plan of subdivision;
WHEREAS Section 8 (1) of the Municipal Act, 2001, S.O. 2001, c. 25, as
amended. provides that the powers of a municipality under this or any other Act
shall be interpreted broadly so as to confer broad authority on the municipality to
enable the munIcipality to govem its affairs as it considers appropriate and to
enhance the municipality's ability to respond to municipal issues
AND WHEREAS pursuant to the said Municipal Act, Section 9 provides that a
municipallty has the capacity, rights, powers and privileges of a natural person
for the purpose of exercising its authority under this or any other Act;
AND WHEREAS the Council for The Corporation of the Municipality of
Kincardine deems it advisable to enter into a subdivision agreement with
1582679 Ontario Inc. for that property being composed of Part of Lots A, Band
C, Concession A, geographic Township of Kincardine, Municipality of Kincardine;
NOW THEREFORE the Council for The Corporation of the Municipality of
Kincardine ENACTS as follows:
1. That The Corporation of the Municipality of Kincardine enter into a
subdivision agreement WIth 1582679 Ontario Inc. to ensure appropriate
development of those lands described as Part of Lots A, Band C,
Concession A, geographic Township of Kincardine, Municipality of
Kincardine and being more particularly described in the subdivision
agreement attached to this by-law as Schedule "A"
/2
.
.
.
.
Page 2
1582679 Ontario Inc. (Lakefield Estates) Subdivision Agreement By-law
By-lawNo.2007 276
2.
That the Mayor and Chief Administrative Officer be authorized to sign, on
behalf of The Corporation of the Municipality of Kincardine, the subdivision
agreement with Mystic Cove Developments Inc., attached to this By-law
as Schedule "A", as well as any other documents required to bind the
Corporation relating to this subdivision.
4. This By-law takes effect from the date of passage by Council and comes
into force and effect pursuant to the provisions of the Planning Act. 1990.
5. This by-law may be cited as the "1582679 Ontario Inc. (Lakefield Estates)
Subdivision Agreement By-law"
READ a FIRST and SECOND time this 19lhday of September 2007
.'.- '
Q'
~-Mw-~T
READ a THIRD time and FINALLY PASSED this 19th day of September 2007.
I J
,
/'7
~
~-j~~~'
,
,
F:lwp\0613S\o7Sepll9-Lak.ficldUIbanRes;dentialAgreemont.doc
r 'J1;,cdE5'Jt:,,,,,..zi. to Ily-taw -
,No. passedthe~'day
OC- od;i-
~~bk'rQ{
Ciod< ..:io4
CORPORATION OF THE MUNICIPALITY OF KINCARDINE
SUBDIVISION AGREEMENT
FORLAKEFIELD ESTATES SUBDIVISION
between
15826790ntariolne.
=d
THE CORPORATION OF THE MUNICIPALITY OF KINCARDINE
The Corporation of the MurucipalityofKincardine
1475 Concession 5, R. R. 5
Kincardine,Ontario
N2Z2X6
THE CORPORATION OF THE MUNICIPALITY OF KINCARDINE
INDEX
Seetionl-Interpretation........._..............................__.......................................................2
1.1 Definitions....................................................................................................................2
1..2 ListofSclredules.............,_...........................................................................................3
Section 2-0nler ofProeedure.............._............................ ............_._......................3
Section3-lnstallationofServices............._..o.._................................................_..................5
3.1 General.........................................................................................,. .....................5
3.2 Municipality's Legal and Engineering Costs...................................................... ..5
3.3 Developer's Engineer....................................................... ..................,.........................5
3.4 WorkstobeInstalled....................................,..............................................................6
3.5 ApprovalofPlans.............................................................................................,.."...,..6
3.6 Notifieation ofCOmmeneemenL.................."'._..........................................................6
3.7 Progress of Works...................................................... ..................................................6
3.8 Scheduling of Works.................................................... ................................................7
3.9 Contractor....................................................................................................................7
3.10 Utility Costs and Charges.............................................. ..............................................7
3.11 Access Roads.................".................................... .........,..............................................7
3_12 Movement ofFill......................................................................................................... 7
3.13 Damage to Existing Plant.............................................................................................8
3.14 Signs.............................................................................................................................8
3.15 Testing..._______._._............................................................................................................8
3.16 Erosion and Silting Conlrol................................................ ..................... ........8
3.17 Emergency Access.......................................................................................................8
3.18 Construction RefuseandWeeds.................................................... ........,.........,..,.,...,..8
3.19 DustControL.... .9
3.20 Street Names...................................................... ................................................,."...,,,9
3.21 Mumdpal Street Numbers...........................................................................................9
3.22 Blasting.....................................................................................................................,..9
3.23 Driveways............................................................................................................".....,9
3.24 Contaminants.............................................................................................................10
Section 4_Acceptance of Works..................................
.............................................10
4.1 Stages of Construction and Services...................................................... ....................10
4.2 Inspection andAcceptance of the Works.............................................................. .....10
4.3 Final Acceptance of the Works................................................ ...............................",10
4.4 Acceptance During Winter Months........................ .11
4.5 Use of Works by Munidpality................................................................ ...................11
4.6 Replacement of Survey Bars......................................................................................11
4.7 Ownership of Services .................................".".........................................................11
Section5-l\IaintenaneeofWorks........................................_..._.......................................11
5.1 Maintenance of Works...................,................................... ........................................11
5.2 RoadIvlalntenance................................................................................_....................12
5.3 Emergency Repairs .............................................,......................................................12
Sect10n 6_DraInage llnd Landscape Design.-:--.._........................................... ................12
6.1 Drainage..............................................................................................................._..12
6.2 Preservation of Trees..................................................................... ..........................12
6.3 Lots Unsuitable for Building ........................................................,............................13
6.4 Lot Grading.................... .13
6.5 Maintenance ofLo! Grading......................................................................................15
Index (cont'dl
Section7-LandstobeConveyed................................
...............................................15
7.1 Lands for Municipal Purposes ...................................................................................15
7.2 Easements....................................................................._............................................15
7.3 Turning Circles ..........................._.._...........................................................................15
Section 8 - AdministratioD...............................;._...._.......................................___.........16
8.1 Voidmg Agreement....................................................................................................11>
8.2 Developer's Expense ................,................................................................................16
8.3Ph~sing.......................................................................................................................16
8.4 Developer's Liabilities...................................... .........................................................16
8.5 Insnrance....................................................................................................................17
8.6 Legal Notice to Developer .........................................................................................17
87 Registration................................................................................................................17
8.8 MortgageslEncumbrances..........................................................................................17
8.9 Requirements for Bnildlng Permits..................................................... ......................17
8.10 Requirements for OOCUp!lIlCy.....................................................................................18
8.11 Special Building PennitslModel Homes....................................................................19
8.12 RighttoEnterintoanAgreement..............................................................................19
8.13 SnccessorsandAssigns........................................................___..._.....__._....................19
8.14 Notification to Purchaser......................................................... ..................................19
8.15 Schedulmg, Progress and Completion.......................................................................20
8.16 No Municipal Liability ..20
8.17 Assigmnent................................................................................................................20
8.18 Conflict .......................................................................,........................................20
i(19 Severability ..20
8.20 Amendment ................................................................................. .............................20
8.21 Further Assunmces.....................................................................................................21
8.22 Joint and Several...................................................... ..................................................21
Section 9-FinanciaJ Proviskms............._..._............................... ..........__............21
9.1 Development Charges, Drainage and Local Improvement Charges..........................21
9.2 Secnrities....................................................................................................................21
9.3 ReductionofSecnrities........................................................................................... ..22
9.4 Statlltory Declaration ofAcoounts Paid.................................................. ...................22
9.5 ConslruCtionLienAct................................................................................................23
9.6 Partial Release..................................................................... .......................................23
SectionlO-SpecialProvisions
-SeeSehedule~M"
...._._............................................__...................23
Section l1_Signatures.....................
....................................._.............._..................24
Index (cont'd)
LIST OF SCHEDULES
Schedule 'A"
Description of Lands Being Snbdivirred........................... ..............................25
Schedule "B" - Plan of Subdivision....................................................... ...................................26
Schedule"C"
Mnnicipal Servicing Standards.................................................... ....................17
Schedule"D"
Checklist of Works 10 be Constructed.............................................................39
Schedule"'E"
Itemized Estimate ofCosls of Construction of Bach Part of the Works..........40
Schedule"F"
List of Lots Unsuitable for Building Purposes ................................................41
Schedule "G" - Owner s Final Grading Certificate...................................................................42
Schedule "H" List of Lands for Municipal Purposes and Easements to be Granted
to the Mnnicipality............................................... ............................................43
Schedule"r' NoOccupancyAgreement...............................................................................44
Schedule 'r' ApplicationforReductionofSecurity.............................................................45
Schedule "K" Form of Partial Release................................................................ ...................46
Schedule "L" Conditions ofDraftApproval...................................................... ....._.............47
Schedule"M:" Special Provisions................................................... .........................................50
MUNICIPALIIYOF KINCARDINE
LAKEFlELD ESTATES SUBDIVISION AGREEMENT
THIS AGREEMENT made in triplicate on thel9'hday of September, 2007A.D.
BETWEEN:
1582679 Ontario Inc.
hereinafter ~alled the ~Developer" of the FIRST PART
-""'-
THE CORPORATION OF THE MUNICIPALITY OF KINCARDINE
hereinafter called the ~Municipality" oflbe SECOND PART
WHEREAS the Developer is the owner of the Land described in Schedule ~A~ to this
Subdivision Agreement thereinafter called the 'Agreement~) and proposes to subdivide it for the
purposeofselliug, conveying, or leasing it in lots, by reference to a Registered Plan of
Snbdivision.
AND WHEREAS the Developer declares that it is the registered owner of the lands and has
appl1ed to the County ofBmce (hercinaftercalled the "County), for approval of aPlan of
Subdivision (hereinafter called the ~Plan "), which is annexed hereto as Schedule "'B~ to this
Agreement.
AND WHEREAS the Mnnicipahty has been anthorized by the County to require the Developer
to agree 10 construct and install certain municipal services as hereinafter provided and herein
referred to as the "Works" set out in Schedule '"D" and to make financial arrangements with the
Municipality for the installation and construction of required Serv1ces before final approval of the
Plan by the County.
AND WHEREAS the Developer is required to dedicate for public purposes certain portions of
the Lands or make a cash payment to the Municipality in lieu of dedicating such land.
AND WHEREAS the word "Developer'" where used in thisAgreement includes an individual,
anAssociation,aPartnership,oraCorporntionandwhereverthesinguiarisnsedherein,itshall
be construed as including the pluraL
NOW THEREFORE THIS AGREEMENT WiINESSETII that ill consideration of other good
and valuable consideration and the sum of One Dollar ($1.00) of lawful money ofeanada, now
paldby each of the parties hereto to each of the otherpartieshereto, (the receipt whereof is
hereby acknowledged), the parties hereto hereby covenant, promise and agree with each other as
follows:
2
SECTION 1 INTERPRETATION
1.1 Definitioll$
Thetenns defined in this Section 1.1 sha1l have the followmgmeanings unless the contex:t
expressly or by necessary implication otherwise requires:
"Agreement" means this Agreement titled "Subdivision Agreement'"
"Business Day'" means any day tbat is not a Saturday, Sunday or statutory holiday in the
Province of Ontario.
"Certificate of Final Acceptance" means the certificate issued by the Municipality after
satisfaction of the conditions identified in Section 4.3.
"Certificate of Inspection Re: Readiness for Occupancy" means the certificate issued by the
MunicipalityaftersatisfactionoftheconditionsidentifiedinSecti0ll8.1O.
"Certificate o{Preliminary Mceptanee" means the certificate issued by the Municipality after
satisfaction of the conditions identified in Section4.2.
"Chief Admlltistl-ative Officer (CAO)" means the Chief Administrative Officer or hisllrer
designate for the Municipality of Kincardine.
"CWefBuildIng Official (CBO)" means the Chief Building Official or designate for the
MumcipalityofKincardine.
"Conservation Authority" means the Saugeen Valley Conservation Authority and its
successors and assigus.
~County" means the County of Bruce and its successors and assigns.
"Damage/Lot Grading Dep<l$it" means the amount of$2,500.00 per lot orblock shall be paid
by the Developer or Owner to the Municipality by way of cash or letter of credtt as described ill
Section 8.9 of this Agreement.
"Developer" means, collectively, 1582679 Ontario Inc. and their respective successors and
assigns.
"Land"means the real property which is the subject of the Pian,the legal description of which is
attached as Schedule "A"
"Municipality" means the CorporatIOn of the Municipality of Kincardine, and its successors and
assigns.
"Owner" means the Owner ofa lot or block and may include the "Developer"
"Plao":rneaIlS the plan ofsubdivoooo relating to the Land, a draft copy of which is attached as
Schedule "B"
"Public Works Manager" means the Public Works Manager or his designate for the
Municipality of Kincardine.
"Works" means the works and services described in Schedule "D"
3
1.2 List of Schedules
The following schedules are attached to and form part of this Agreement:
Schedule "A"
Schedule"B"
Schedulc""C"
Schedule"D"
Schedule 'E"
Schedule"F"
Schedule "0"
Scbedule"H"
Schedule "I"
Schedule']"
Schedulc"K"
Schedule"L"
Schedule"M"
Description of Lands Being Subdivided
P!:lnofSubdivision
Municipal Servicing Standards
Checklist of Works 10 be Constructed
Itemized Estimate orCosts of Construction or Each Part of the Works
List of Lots Unsuitable forBuiJdingPurposes
OwnersFinalGradingCertificate
Lisl of Lands for Municipal P\u]:loses and Easements to be Granted
to the Municipality
No Occupancy Agreement
Applicationfor Reduction of Security
FonnofPartiallU:lease
Conditions of Draft Approval
Special Provisions
SECTION 2 - ORDER OF PROCEDURE
2.1 Upon application to the MuniclplllilY for the preparation of an Agreement the Developer
",,",
(a) Pay to the Municipality the sum oflen thousand ($10,000.00) dollars as a deposit
in respect of the Municipality s legal and engineering oosts referred to in Section
3.2 (a) herein.
(b) Submit a General Plan ffiltlining the seJ;Vlces to be installed.
(c) And maybe required to signa predevelopment agreement which includ<ls:
. the intent of the dev<lloper;
. the intent of the Municipality;
. astattlmentffiltlininglhe areas of study that will be required prior to the
Municipality agreeing 10 proceed with the deve!opmem (by means ofa
developmentagreernent);
. a statement outlining the deposit amount of$10.000 and the terms of Its use;
. ageneraltimelineforreviewofthedevelopmentproject.
2.2 Prior to Registedng the Agreementthe Developer shall:
tal Depositwith the Municipality Securities and Insurance as outlinedinthe
Agreement.
(b) Pay in full any outstanding taxes or drainage, locai improvement charges and
charges under the Municipal Act including outstanding sewer rates andlorwater
rales.
4
(0) Mutually agree with the Municipality on the parcel of land to be deeded to the
Municipality forparkland or the amount of cash to be given to the Municipality
in lieu of Parkland.
(d) Pay the amount m heu of parkland to the Municipality or deposit the
TransferslDeeds of Land for the parkland with the Municipality.
(e) Provide proof of postponement of any encumbrances on the lands_
(f) Deposit with the Municipality's Solicitor, copies of this Agreement executed by
the Developer, to be executed by the Municipality and retain"d by the
Municipality's SolicitDrfor registration as hereinafter provided.
(g) DelivertotheMunicipality'sSolicitorwrittenauthorizationtoregisterthls
Agreement or Notice of this Agreement both before and after regislrlllion uftbe
Plan, and a cheque in respect of the cost of the said registrations where upon the
Mtmicipality's Solicitor shall ~gisterthis Agreement.
2.3 PriOl-to starting constructioD on the Serviee$, the Developer shall:
(a) Have obtained final approval of the Plan from Ihe County and have obtained
Registration offue Plan.
(b) Deposit exlll-'\lted deeds to theMurucipahty,:free and clear of all en.::umbr$lces,
for any lands to be conveyedtq the Municipality (and snch deeds to be deposited
with the Municipality) prior to the CAO's clearance letter to the County of
Bruce.
lc) Have submitted and obtained th\) written approval ufthe Municipality s Engineer
for the following all to be done in accordance with the Municipal Servicing
Standards of the Municipality:
. The Drainage Plan;
. The Lot Grading Plan;
. The Service Layout Plan for underground electrical services, telephone, gas,
etc.;
. Final approved drawings for all Works requrred in Schedule "D"to this
Agreement.
(C) Submit to the Municipality the Ministry of the Environment's Certificate of
Approval for the Water Supply and Distribution System, the Sewage Collection
System, and the Storm Sewer System and Stonn Water Management Works.
(d) ProvidewrillenconfinnationofhavIDgobtainedtheapprovalfordrainage,road
crossings,encroachment.etc. ofall road authorities mcluding the Municipality,
County, Conservation Authority, the Ministry of Transportation of Ontario and
any other authority involved.
2.4 Prior to the sale of any lot audlor -prior to the issuance of building pernnts the
Developer shall:
(a) Have complied with all requir~nts of Section 8.9.
2.5 Prior to any person occupying any building, the Developer shall:
(al Have complied with all the requirements of Section 8.10 of this Agreement.
5
SECTION 3 _ INSTALLATION OF SERVICES
3.1 General
Upon approval of the Plan by the CoUnty, the Developer shall design, construct and
install at his own expense and in good workmanlike manner to fue servicing standards
of the Municipality as set out in Schedule "C~ to this Agreement.
3.2 Municipality's Legalaod Engineering Costs
(a) The Developer agrees to pay the Municipality's cost ofthe Municipal Solicitor
and of the Municipality's Engineer's invoices forlhe checking of plans and
specifications and for supervision and inspection on behalf of the Municipality.
(b) The Developer shaIl be invoiced regularly by Ihe Municipality for all costs
incurred by the Municipality with respect 10 this Agreement.
(0) The Developer shall reimburse the Mumcipality for all costs incurred by the
Municipality as referred to in Section 3.2 (al herein, within thirty (30) days of
ea<::h billing. failing which the Municipality and its agents shall cease all work
with respect to the review of the Subdivision.
(d) The deposit referred to in Section 2.1 (a) of this Agn=nent shall be retamed by
the Municipality as a float against any unpaid hills and such deposit (or the
balance thereof, ifany) shall be returned to the Developet at Final Acceptance of
the Subdivision by theMunicipality and the Municipalitybeing satisfie<iin its
discretion, that all cosls in Section J.2 (a) herein and any contingencies with
respect to the SnbdiVlsion have been paid in full.
(e) The Developer shall pay to the Municipality, on thirty (30) days written notice
from the Municipality, such amount as is necessary to maintain the deposit
referred to in Section 2.1 atthesumoftenthousand($lO,OOO.OO}dollars,failing
which the Municipality and ns agents shall cease all work with respect to the
review of the Subdivision.
3.3 Developer's Engineer
The Developer shall employ engineers registered with Professional Engineers Ontario
and approved by the Municipality:
(.,
To prepare designs;
(b)
To prepare andfumish all required drawings;
'0)
To prepare the necessary contract(s);
To obtain the necessary approvals in conjunction with the Municipality, the
County Health Unit and the Ministry of the Envirorunent, and others as required.
To provide the field layout, the conIraCt documentmion and the full time
superviSIOn of construction.
To maintain all records of construction and upon completion, to advise the
Municipality s Engineer of all construction changes and to prepare fmal "as
constructed" drawings. Digital files of the 'asconstmcted" drawings shall be
submitted to the Municipal Engineer and the Municipalityprior to the issuance of
Ihe Certificate of Final Accepllince. Digital files shallbe in the fOrD13t of
AuloCAD dxf or dwg files, coordinates ofUTM Narl 27 zone 17 North or UTM
Nad 83 zone Norrh with and accuracy ofl meter or less.
(d)
(0'
(0
(gJ
To act:l.Slherepresental:1veoffueDeve!operin all matters pertaining to Ihe
construction.
6
(h) To provide co-ordination and scheduling to complYWlth the timing provisions of
this Agreement and the requirements oflhe Municipality's Engineer, for all
works specified in this Agreement
(i) To provide certification that the installation ofservices was in conformance to
said plans and speci:fications, sullli certification to be in a fonn acceptable to tbe
Municipality s Solicitor and the Muriicipality'sEngineer.
(j) TotakesuchotheractionsasmayberequiredbytheMunicipaJity,acting
reasonably, for Ibe completion of the subdivision in accordance with tins
Agreement and good engineering practices.
3.4 Works to be Installed
The Works to be installed are setout in Schedule "D" to this Agreement This schedule
isto set out the works in general 1entiS'only and shall not be construed as covering all
items in detail. If at any time and from time to time during the development, the
Municipality sEngineeris of the opinion that additional works are necessary 10 provide
adequately any of the public services required by the Plan,the Developer shall, at his
expense, construct, install or perform such additional works attherequest of the
Municipality's Engineer.
3.5 Approval of Plans
The detailed plans and specifications of all services must be submitted by the
Developer to the Municipality s Engineer for endorsement of approval and such
endorsement of approval shall in no way absolve the Developer or its consulting
Engineers ofresponsibiJity for errors inor0111issions from such plans and
specifications.
3.6 Notification ofCommeneemtmt
The Developer shall not commence the construction of any of the works until the plan
has been registered and the Devel<iper has provided 72 hours written notice to the
Municipality's Engineerofhis intenlto commence work. Should, for anyreason, there
be a cessation or interruption ofcoustruction, the Developer shall provide 72 hours
written notification to the Municipality's Engineer before work is resumed.
3.7 Progress of Works
The Developer shall install all Works iu a timely manner, in accordance with the
requirements of Schedule "C"andtbisAgreement. Ifhe fails to do so, having
commenced to install the aforesaidworks,fails orueglects to proceed with reasonable
speed, or in the event that the aforesliidworks are not being installed in the manner
requiredbytheMunicipality,thenupontheMunicipalitygivingseven(7) days written
notice byprepaid registered mail to the Deveioper, the Municlpal1ty may, without
further notice, enter upon the sliid landS andproceedto supply all materials and to do
all the necessary works in connection With the installation of the said works, inclnding
the repliir or reconstruction offuult work and the replacement of materials not in
accordance with the speciiications, andto charge the costthereoflogetberwithan
engineering fee often percent (10%) of the cost of such malerials and works to the
Developer who shall forthwith pay the same upon demand. If the Developer fails to
pay the Municipality within thirty (30) days of date on the bill, the money owing may
be deducted fi:om the cash deposit, lett<llSofcredit, or other securities. It is understood
in the event that the MunicipalitymllSt enter upon said lands and have works completed
or repaired due to situatiousas outlined above any or all originalmylars and
specifications preparedbyth" Developer's Engineer mnst be turned over to the
Municipality's Engineer for his use should he reqnire same. !tisunderstuodandagreed
betweentheparties hereto that such entry upon the lands shall be as agent for the
Developer and shaH not be deemed for any purpose whatsoever, as an acceptanreor
assumption of the said Works by theMunicipality. The Mnnldpality, in addition 10 all
other remedies may refuse 10 issue building perrnits lID.tii such Works are complelely
installed in accordance with the requirements of the Municipality.
7
Without limiting the obligations ofihe Developer herein, lithe Developer shall default
on the performance of any term, covenant or provision of this Agreement and if such
default shall continue for ten (10) days llfter the Developer receives written notice of
such deiaultby the Municipality (orsuch shorter time as may be required m the cases
of an emergency or other urgtTIlt matters or as otherwise provided for herein), the
Municipality may perform that obligation on the Developer's behalfand may enter onto
the lands constituting the Plan forthis purpose. If the Municipality is compelled or
elects to incur lIIly expense in connection with its performance of the Developer's
obligations (including any engineering or legal fees incurred in connection with such
actionsl,anyreasonablecostssoincurredbytheMunicipality,togetherwithallinterest
thereon and any damages incurred, shall be payable by the Developer and shall be
collectible by the Municipality in like manner as municipal taXes. The Developer also
acknowledges and agrees iliatthe Municipality has the right to draw down any Letters
of Credit, cash or other security forlhe purpose of collecting any such expenses
incurred by the Municipality.
3.8 ScbedulingofWorks
Prior to the start of construction and prior to the issuance of building permits, the
Developer shall supply for the approval of the Municipality's Engineer a Schedule of
Works setting out the order in wbich be cousiders the various sections of the works
within the Plan will be built. The Municipality s Engineer may amend this schedule
and the Developer must construct, install or perform the work as the Municipality's
Engineer from time to time may direct.
3.9 Contractor
The said services shall be installed by, a contractor or contractors retained by the
Developer and approved in writing by 1;111' Municipality s Engineer.
3.10 Utility Costs and Charges
The Developer shall deal directly with all Utility companies. He or his Consulting
Engineer, shall obtain all approvals andpermits and pay all fees and charges directly to
the appropriate Utility.
3,n AccessRoads
All access roads must be maintained by the Developer in good repair acceptable to the
Municipality's EngineolI during the time of construction, This shall include the removal
of mud tracked from the Subdivision as well as dust control. No roadway outSJ.de the
ljroits of the proposed Subdivision maybe closed without the written consoot of the
Municipality. To obtain such consent, the DevelopolI shall advise the Chief
AdU1imstrative Officer(CAO), not laterthan 14 days prior to the proposed closure, of
the date, time and duration they wish tq.close a roadway. All costs for advertising the
closure and signage shall be bome by,the Developer. The Municipality reserves the
right to lnnit or prohibll the use of any existing access road by the Developer.
3.12 Movement of Fill
The Developer covenants and agrees that it shall not dump norpemrit to be dumped
any fill or debris on, nor shall it remove or permit to be removed any fill, topsoil. trees
orshrubs from any public lands,other than roads,withoutthe written consent of the
Municipality's Engineer. The Developer further agrees that uo topsoil shall be
removed from the lots and/or blocks eil:cept for construction purposes within the
developrnent and then such topsoil sl)l!ll be stocl...piled during grnding operations aud as
each building is complcted,the top,soil so stockpiled shall be replaced on the ground
around each building to comply with the Municipal standards,and the replacing of such
topsoil shall include aU surfaces not covered by buildings, driveways or pavement
withm the development. Excess topsoil may be removed from the site with the
approval of the :Municipality's Public Works Manager.
8
3.13 Damage to Existing Plant
The Developer shall repair any d!lIIlllge caused to any existing road, road allowance or
existing structure orplant located,onthe road allowance as a result of the development
and shall pay fur any costs involved m. relocation of existing service such as hydrants,
tel<:pbonepoles, hydro poles, pad mounl transformers, cnbicles andpedestals,etc.,
whichmay be necessary because oflhe development.
3.14 Signs
Sigus at least 1.2 mx U: m shall be erected bylhe Developer in an approved location
at each entrance to the Subdivision..The signs shall read as follows:
"Roads Not Assumed by Municipality _ Use at Your Own Risk"
These signs shall be installed prior to the start of construction and be removed after all
the roads have received a Certificate ofFiual Acceptance.
3.15 Testing
The Municipality s Engineer may have any qualitative or quantitative tests made of any
materials which have been or are proposed to be Il8ed in the constructionofany of the
wurks required by this Agreement, or may require additional television camera or soil
tests to be carried out, and the cost ofsuch tests shall be paid by the l)eveloperwithin
ten days of the account being rendered by the Municipality. Nothing herein shall
relieve the Developer of its responsibility to carry out any tests required by good
engineeringprnctice,
3.16 ErosloollodSiltiDgControl
The Developermust take all neceSS81yprecaUtiOns to prevent erosion and
Stldimentation of sewers, ditches, culverts, slopes, etc., both within the Development
and downstream during construction.and completion of servicing. Failing adequate
precautions being taken. the Developer will be responsible for correcting any damages
and pllying all maintenance,;osts resulting therefrom.
3.17 Emergency Access
The Developer shall at all times during construction and development of the Works
maintain emergency access to the la:nd:to the satisfaction of the Municipality's
Engineer.
3.18 Construction Refuse and Weeds
The Developer, and each subsequent Owner of Lots or Blocks within the Plan, shall
regularly dispose of all construction refuse. debris or weeds whether it be from site
servicing or house building or any other source relaledto the development of the site. in
an orderly and sanitary fashion.. lfthe Developer or subsequent Owner of the Lots or
Blocks within the Pla:n fails to remove and dispose of construction refuse. debris or
weeds tu the satisfaction of the Municipality's By-law Officer, the Municipality may
give writkn notice to the Developer or lot Owner. If the Developer or each subsequent
Owner of Lots or Blocks within the Plan fails to dispose of the refuse. debris or weeds
witbin forty-eight (48) hours after receiving a written request from the Municipality to
do so. the Municipality may, without further notice, undertake such removal and
dispostuon and the cost thereofshaIl be paid by the Developer or each subsequent
Owner of the Lots or Blocks within the Plan forthwith upon demand. which costs shall
include all <:Xpellses mcurred by the Municipality in carrying out such removal and
disposition. The burning of construction refuse, debris or weeds, whether it be from
site servicing or house building or an)' other source related to the development of the
site on any lands withmthe Plan is prohibited..
9
3.19 Dust Control
Until the Final Acceptance of all SeIVices 10 be constructed under this Agreement, the
Developer shall use such reasonable method to prevent any dust problem to traffic Or
home occupants as the Municipality shall deem necessary and for this purpose the
Public Works Manager shall notify !he Developerin writing from time to time of1he
requirements of the Municipality.
3.20 Street Namcs
The Developer shall name all streets within the Land forming partofthe Plan with
names approved by the Municipality.
3.21 Municipal Street Numbers
(a) All Lot, Block or building numbers fur use within the Plan shall be allocated by
the Chief Building Official (CEO). To obtain such allocation, the Developer
shall furnish the CEO with a copy of the Plan as registered upon which the CBO
will designatt: the proper numbers for each Lot, Block or buildmg.
(b) The Developer shall display by means ofa legible sign at least I' x I' to be
erected on each Lot or Blockwilhinthe'Plan. the Lot or Block nwnber as shown
on the Plan and the street number and Lot or Block number for each Lot or Block
prior to the issuance of a Building Permit for that Lot or Block which sign shall
remain until such time as the building on such Lot or Block is occupied in
accordance with the provisions of this Agreement_
(c) Each Owner shall cause the street number so provided to be placed and
maintained in a conspicwms position in the front of the property upon occupancy.
3.22 Blasting
The Developer agrees that no blasting will be undertaken without the wntten consent of
the Municipal Engineer.
3.23 Driveways
The Developer hereby agrees that the driveways for all lots will be in " location and
have a widfu and design as may be approved by the Municipality_ Without in any way
limiting the discretion of the Municipality, the location of the driveways may be further
limited by special revision in Schedule "M" of this Agreement. Further. all driveways
for all lots in the plan should be located in a mannerthatwill minimize the amount of
snow that will accumulate in the lot's driveway. The location of driveways is
particularly important wIth respect to all corner lots located in Ihe plaa as these
driveways entrances must be located as far as possible from the street comer to
minimi2:" the amount of snow that wiij block these driveways during the Municipality's
efforts to remove snow.
Further. the Developerherebyagrees that he will be responsible for, or will provide for
agreem<:nts with subsequent owners, with respect to responsibility, to complete all
driveway entrances, for their fullvridth,vritl1 a hard surface consisting of asphalt or
concrete pavement. This hard surface sball e;<Iend to the edge of the municipal road
allowance.
10
3.24 Contaminants
In the event fue Developer discovers any waste, contarninants,pollutants, hazardous
substances or any other similar substances thatmaybe detrimental to the environment
during the development of the lands constituting fue Plan, the Developer hereby Ilgrees
to notify the Municipality and the Minit;try of the Environment iuunediately and take
aU necessary steps and remedial efforts required by the Ministry of the Enviromnent
and the Municipality to remove such waste, contaminants, pollutants, hazardous
substanus or other substances that could be detrimental to the environment. Intaking
such action, the Developer shall fulfill all legislative requirements for the remediation
and clean up of lands constituting the Plan and shall comply with all1egislative
requirements regulating the removal, transportation and disposal of such waste,
contaminants, pollutants, hazardous substances or any olher similar substances from the
said lands.
SECllON 4 - ACCEPTANCE OF WORKS,
4.1 StagesofConstructionandSenice$
The Municipality will grant Preliminary or Final Acceptance of servicing based upon
three (3) stages of construction; and when the development is phased, within the whole
of each phase as approved by the Municipality. Stages of construction are as follows:
\a) Stage I consists of all undergmund Works including storm sewers and storm
water management facilities; sanitary sewers, watermains and the completion of
Granular "B~ road base and a portion of the Granular "A" for a riding surface.
(b) Stage2-services shall include the balance of the roadworks including granular,
curbsandgutter,baseasphalt,gradingofboulevardareas,constructionofall
drainage swales and outlets. sideiNalks,installation of street and traffic signs,
conduits, piping and facilities for the completion of electrical servicing, street
lighting and other utilities such as gas, telephone and Cable T.V
(c) Stage 3 ~ services including the final coat of asphalt, topsoil and sodding, trees,
fencing and any other requirements of this agreement.
4.2 Inspection and Acceptanee of the Works
When all of the services in any stage of servicing as identified above have been
completed and the Municipality's Engineerhas been given written certification by the
Developer's Engineer that such services havebee.u constructed in each stage in
accordance with the approved plans and specifications in this Agreement and upon
satisfactory inspection by the Municii>&lity's Engineer, the Municipality's Engineerwill
n::connnend that the Municipality grant a Certificate ofPrelirninary Acreptance. This
Certificate may include a list of minor deficiencies which the Developer must repair.
The services shall then be subject to a guarnnteed maintenance period as described m
SectionS.!.
4.3 Final Aeeeptance ofthe Works
On receipt of a written request from the Developer for fmal inspection and final
acceptance following completion of the guaranteed maintenanee period outlined in
Section 5.1. the Municipality's Engit).eerwill oomplete an inspection and if there are no
deficiencies, will recommend to the Municipality that the Certificate of Final
Acceptance be issued. This Certificate will be issued provided that the Developerhas
paid ali accounts to the Municipaliiy aJ?-d the Municipality is:
Satis:fiedthe applicable services have been completely installed;
Satisfied all repau:s or maintenance work on the applicable services have been
completed.
II
IlI1dthe MunicipalityhllS:
Approved the formal certification offinal completion from the Developer's
Engineer certifYing that all Works andserv:ices have been installed;
Received as-built drawings as detailed elsewhere in this Agreement.
4.4 Acceptance During Winter Months,
The MunicipalitywilJ Dotbe required toprovide Certlficates ofPre1iminary or Finnl
Acceptatlceduringthewintermonthsoranyothertimeofyearwheninspectionofthe
Works and services is 1mpral.'tical due to snow cover or other adverse conmtions.
4.5 Use of Works by Municipality
The Developer agrees that:
la) The Works maybe used prior/o acceptance by the Municipality, or other
authorized persons for the purposes for which such works were designed.
(b) Such use shall not be deemed an acceptance of the Works by the Mumcipality.
(c) Such use shall not in any way relieve tbe Developer of his obligations in
respect of the oonstruction andmaintenance of the Works soused.
4.6 Rt:placement of Survey Bars
Prior to the final acceptance by the Municipality,the Developer shall deliver to the
ChiefBuildmg Official (CBO) a statement from an Ontario Land Surveyor that after
tbe completion of the work,be bas,fOlmd,insatisfactory condition or replaced all
survey monuments and iron bars as sbown on the registered plan.
4.7 OwnersbipofServtces
Upon the issuance to the Thlveloper of the Certificale of Final Acceptance, the
ownership of the services descnlled sha11 vest in the Municipality and the Developer
shall have no claim or rights thereto ex(;ept those occurring as an owner of the lands
abutting the streets where sucbservices are installed.
SECTION 5 _ MAINTENANCE OF WORKS
5.1 Maintenance of Works
The Developer will be responsible for the repair and maintenance of all services
including hydro costs for streetlights, until a Certificate of Final Acceptance Is issued
by the Municipality. This maint.maD.e;e period shall exlendfortwo (2) years from the
date of the Certificate of Preliminary AccePtance for each Stage of the Works. During
this maintenance period, a 10% security holdback shall be retained by the Municipality
in aooordance with theprovisioils of Clause 9.3 <e) of this agreement. Ifdunngthis
period, the Developer fails to carry out maintenance work within seventy-two (72)
hours after receipt of the request from the Municrpality,then the Municipality's
Engineer or Public Works Managermay, without further notice, undertake snch
maintenance workand the tatal custs of such work. inclnding engineering fees,sball be
borne by the Developer. If the Developer fails to pay the Municipality within thirty
(301 days oflbe date ofblllingthen Ibe money owing maybe deducted from the
deposited securities. Towards the end: of the Maintenance Period. the Developer shall
make written request to the Municipahty for a final inspection to be made in respect to
the issuance of the Certi:ficate of Final Acr:eptance.
12
5.2 Road Maintenance
The Developer will be responsible for the maintenance of the roads unttl final
acceptance.
Slll1llllt:rmaintenance shall include grading, dust control and general clean-up of the
Site. Winter road 1llll1lltenance shall include allplowmg, sanding and salting to assure
proper vehicular access within the Subdivision.
In the event that proper maintenance or snow removal is not provided by the Developer,
the Municipality,through its servants, contractors oragents may provide maintenance
and/or remove snow-without notice to the Developer. Such workvrill be carried out at
times deemed to be an emergency by the Public Works Manager. All costs ofsuch
work shall be paid by the Developerwithin thirty (30) days ofdate ofbillmg or
otherwise may be deducted from the deposited securities. The Developer further agrees
Ihat any work done by the MunicipaIitj pursuanl to this contract before the roads are
accepted by the Municipality sball not be deemed in any way, to be an acceptance by
the Mumcipality of the roads in the said Subdivision upon which such work is done.
The Developer acknowledges that the Municipality, in providing maintenance or during
snow removal, may damage or interfere with the works of the Developer and cause
damage to such works and the Developer hereby waives all claims against the
Municipality that he might have arising therefrom and covenants that he will make no
claim against the Municipality .for sucli interference or damage. Representation may be
made requesting that the Municipality consider entering into a separate Agreement with
the Developer to undertake the winter road maintenance within the Subdivision.
5.3 EmergeneyRepairs
Employees Or agents of the Municipality may enter outo the Land at any time or from
time to lime forthe purpose ofmaking emergency repairs to any of the Works. Such
entry and repairing shall nof be deemed an acceptance ofany of the Workshy the
Municipality Or an assumption by the Municipality of any liability in connection
therewithorareleaseoftheDeveloperfromanyofhisobligationsunderthis
Agreement.
SECTION 6 _ DRAINAGE AND LANDSCAPE DESIGN
6.1 Drainage
All Lots and Blocks wlthin the Plan and all lands abutting the Plan shall be graded to
drain in acoordance wlth the Drainage Plan as approved by the Municipality's
Engineer. It is understood and agreed by the parties hereto tbatthe drninage of surface
waters on the Lots and Blocks in the Plan,arethe sole responsibility of the Developer
and subsequent purchasers. and they shall provide and maintain adequate drainage of
such surface works. Satisfactory drainageoutlels shall be provided. Drainageoutlets
shall be constructed from the limits of the Subdivision to a sufficient outlet iu
accordan(:c With the approved engineering drawings.
6.2 Preservation of Trees
The Developer shaH strive to preserve healthy trees, except for the actual area of
roadway construction, the installation of services, or the areas within the building
envelope. No additional trees shall be removed without the Public Works Manager's
writtenpennission.
l~
6..3 Lots Unsuitllble for BuildiDg
Any lol which will require special atterition in order to be serviced will be listed in
Scbedule"F"ofthisAgreement. Priortotlieissuanceofabuildmgpermitforanylot
listed in Schedule '"F', the Developer's.Engineer must submit a letter to the
Municipality s Engineer outlining the measures to be taken to correct the problems on
the lots. This proposal must be approved prior to applying for abuilding permit.
6.4 Lot Grading
All Lands shown within the Plan shall be graded in general conformity with the Lot
GradingPlan,including illl and excavation as required for the full width and length of
the grades and levels,andto the spooifications, requirements and salisfaction of the
Municipality s Engineer; provided that forresidenliallots and blocks, grading must be
brought within zero decimal five (0.5) metres of the final grade and such further
residential development may complete the grading. All work done by the Developer
must be of such a nature as to ensure that the integrity and intent of the overall gradmg
plauisfunctionalunti!theLand~are-fullydeveloped.
(ll) Obligation to Grade Aecordingto Lot Grading Plan
The Lands shall not be graded except in general conformity with the grades
and elevations shown on di" Accepted Grading Plan. The Plan shall bear the
signature and seal of an Ontario Professional Engineerholding a Certificate of
Authorization from Professional Engineers Ontario or who is employed by a
partnershJp or corporation holding such Certificate ofAuthoriution to offer
professional engineeriug sel"liices to the public (hereinafter called a
"Professional Engineer") or a Rflgistered Ontario Land Surveyor who certifies
thereon that the Plan generally confonns with the Lot Grading Plan attached
to the Agreement Or filed WitJithe Municipality's Engineer.
(b) Certified Building Lot Site Plan
Subject to Section 8.9 herein, nobuilding shall be conslrUcledon a Lot or
Blockwithinthe Plan until a Building Lot Site Plan certi:fiedby a Rflgistered
Ontario Land Surveyor or Professional Engineer has been filed with and
approved bvthe Chief Building Official of the Municipality. The Building
Lot Site Plan sball show:
. theprop06ed finished elevation of these lands at each comer of the lot or
bloci<
. the proposed finished elevation of these lands al the front and rearofthe
building;
. the proposed fmished elevations of the underside of the footings and the
proposed finished heightofthe foundation ofthebuilding;
. the proposed finished elevation ofany retaining walls, the proposed
elevation ofany walk-out onto these lands from the basemeut of the
building,andthepmposedfinishedheight of the fmmdationofthe
building;
. theproposedfinishedele,<ationandslopeofanydrivewayandthe
proposedlocationofany~waIeorrearyardcatch basin;
. the location of eavestrough downspouts; no downspouts will be allowed to
discharge in a sideyard hetweenresidences;
. any abrupt changes inthe:proposed finished elevation of these lands;
. the service locations and the invert elevations of all municipal services
. the Lot and Regtslered Plan number, the municipal address for the subject
Lot orBlock and the proposed location ofthebuilding thereon in relation
to the Lot or Blockboundaries.
1be Developer hereby agrees.thatthe existing property line grades abutting
developed lands are not tobe altered ordisturbed,except as approved
otherwise by the Municipality's Engineer.
14
The Developer shall complete such other actions as may be required by the
Municipality,actmgreaslinably,to ensure that the subdivision is deve!opedin
accordance with the tenns of this Agreement and good engineering practices.
(c) Owner's Final Grading Certificate
. The Owner's Final Grading Certificate must be completed in the fDIm
attached as Schedule "G"be!lring the signature and seal ofa Professional
Engmeer or Registered Ontario Land Surveyor that the actual finished
elevation and grading of these lands generally conform with the Lot
Grading Plan andthe Certified Building Lot Site Plan.
. Ifoccupancy occurs between November 1 and May 31 next and an
Owner's Final Grading Certificate is not filed prior to occupancy with the
Municipality's Chief Building Official, then the Owner shall provide the
Municipality's ChiefBuilding:Official with a written undertaking to file
the said Owner s Final Grading Certificate with the Municipality's Chief
Building Official by the fullowingJuneI.
. When the Owner's Final Grading Certificate is accepted by the
Municipality s Chief Building Official that the Lands generally confurm
with the Lot Grading Plm and the Certified Building Lot Site Plan, the
DarnageJLot Grading DepDsitreferred to' in Section 8.9 (h) is returnable to
the Owuer subject to' this. Section!llld Section 8.9 (h) of this Agreement.
. The Owner agrees that, should drainage rectificatiDn become necessary in
the absolute discretiDn of the Municipality, and the Owner fails to make
suchrectrlicatiDnwhensoinstructedbytheMunicipality,the
Municipality may, at its option, undertake the correction of such drainage
and all costs overand above tbetwD thousand, five hundred dollar
($2,500.00) deposit shall be charged back to the Owner and shall include
a management fee Dfl5% of the cost Df labDur and material shall be a
charge against the Lot or Block for which regardmg was carried out and
shall be payable forthwith. the Owner agrees that neither it nDr its
successors or assigns will alterthe grading or change the elevation or
contour Dfthe Land except in accordance with drainage pians approved
by the Municipality.
(d) Obligation to Maintain Grading
After the building or Block is graded in accordance with the Lot Grading Plan
and the Certified Building Lot Site Plan, nO' change shall be made to the actual
finished elevation and grading ofthebuilding Lot or Block in any way that
results in a material alteration ofdtainage on or across thebuilding LDt or
Block or adjacent lands from that shown on the Lot Grading Plan for the
adjacent lands or the Owner's Final Gradmg Certificate for the building Lot or
Block.
(e) Prevention of Surface Water Flow
The Developer and each subsequent owner shall not block, impede. obstruct
orpreventthe flow of surface water as provided for in theDrainage Plan, the
Lot Grading Plan or the Certified Building Lot Site Plan over any LDt Dr
Block by the construction, erectiDn Dr placement thereon Df any damming
device, building. structure 6r other means.
15
(f) Erosion Control
The Developer shall construct silt fences or other facilities as required during
construction to control overland flows fromthis Subdivision 10 ensure that
mud, silt, construction debris; etc. does not adversely affect abutting
properti~s,alltothespecificat:ionsoftheMunicipality'sEngineer.
6.5 Maintenance of Lot Grading
AUlo! grading and drainage facilities and works required by Section 6 or elsewhere in
this agreement shall be provided and maintained by the Developer or subsequent owner
of each individual10t from time to tim,e, in perpetuity at such party's sole risk and
expense.
Should, for any reason, the Developer Of rubsequent Owner fail to maintain that Jot
grading, they acknowledge that the Municipality, in receiving certiiied lot grading
certificates as required inthis agreement, absolves itselfofany further interest or
responsibility for such lor grading save and except for those works on registered
easements.
SECTION 7 - LANDS TO BE CONVEYED
7.1 Lands for Municipal Purposes
The Developer shall convey in fee simple a good title free from tl1lCUIllhrancesto the
Municipal lands for municipal purposes other than roads, which shall be mumally
agre<:d upon by the Owner and the Municipality, or to make a cash payment in lieu
thereofas stipulat.ed by lhe Municipality and also to convey to the Municipality in fee
simple, the 0.3 metre reseIV~S and other lands required by the Municipality. The d~~ds
forthe said lands ate to be approved by the Municlpahty'S SoIicitor and thereafter
forthwith registered and deposited willi the CAD. The cost for preparation and
registration of the said deeds shall be paid by the Developer. A Hstoflandsfor
munidpalpurposes to be conveyed to the Municipality shall be set out in Schedule "H~
of this Agreement.
7.2 Easements
The Developer agrees to grant at his expense all such easements and right-of-ways as
may be reqnired for the installation and supply ofseIVices to the Subdivision. A list of
easernents and right-of-ways to be granted to the Municipality shall be set out in
Schedule "If' of this Agreement.
7.3 T11mingCircles
The Municipality may require the installation of temporary turning circles. Where such
ate required, the Developer shall convey the appropriate blocks to the Municipality for
the purposes ofprovidmg the Municipalitywith sufficient land to constroct said tuming
circlets). The block(s) conveyed to theMweicipality shall only constitute that portion
of land required by the Municipality for the actual roadway of the turning circle. The
temporary turning circle shall be constructed in accordance with Schednle"C" of this
Agreement. The Developer and the Municipality acknowledge that the block(s)
conveyed to lhe Municipality for turning circles shall be reconveyed to the owners in
the eventthatthe street is oonnected in the future. Such conveyance and reconveyance
oftheblockls) shall be completed at no expense to the Municipality. A list of said
blocks is inclnded in Schedule "H" of this Agreernent.
16
SECTION 8 -ADMINISTRATION
8.1 Voiding Agreement
In the event thaI fue Plan is not registered within one year fi:omthe date oflhe signing
of this Agreement, the Municipality may at its option declare this Agreement to' be null
andvoid. All costs incurred shallbe deducted from the deposit paid by the Developer
to the Municipality pursuant tothis Agreement Or any other agreement between the
Developer and the Municipality referred to herein.
8.2 Developer's Expense
EveryprOV1S10ll of this Agreementby which the Developer is obligated in anyway
shall be deemed to include the words "at the expense of the Developer' and "as
approved Or accepted by the Municipality" unless specifically stated otherwise.
8.3 Phasing
(a) The MuniCipality may InStruct the Developerto construct the Works in partkular
phases suitable to' it and the Developermust comply. If the Municipality does
not so instruct the ~eloper, before commencement of any of the Works., he
may request the Municipality's pennissionto divide the area into convenient
phases.
(b) Ifthe construction of the Works is to be phased,then in lieu offunnshing
securities as required by SectiOJi 9 of this Agreement for the whole of the Works
the DtWeloptlT may fumish the tequired securities forthat part of the Works lobe
constructed in each phase{s).
(c) The Land upon which the Works is to be constructed in a fulUrephase shall be
made subject to a specific Holding Zoning (~H") provision by means of a by~law
to be passed by the Municipalityunder Section 36(1) of the Planning Act. R S.
O.1990c.P.13attheDeveloper'sexpense.
(d) Prior to the connnencement of the construction of the Works within the Land
made subject to aHolding Zoning ("H") pravision and after the deposit with the
Municipality of the securities as set ontelsewhere in this Agreement for such
Land along with a writtenrequeSl from the Developer, the Municipality shall at
the Developer's e:>epense pass a by-law under the said Section 36 to remove the
Holding Zoning ("H") provision.
(e) Before proceeding with anadditionalphase the Developer shall obtain the written
approval of the Municipality and no Works shall be permitted to be installed and
no building permits issned Until tbis approval has been given inwritingby the
Municipality.
(f) Subject to Section 8.15 herein, commencement of construction within subsequent
phases of this subdivision, or other subdivisions of the Developerhereinwitbin
tbeMunicipality,maynotproceed.
SA Developer's Liabilities
Until the Municipalityhas issued the Certificate of Final Acceptance for the Works, the
Developer hereby indemnifies and saves harmless the Municipality against all actions,
causes of action, suits, claims and demands whatsoeVer which may arise either directly
or indirectly by reason of the Develop":r undertaking the Plan.
17
8.5 Insurance
The Developer shall insure against all damages or claims for damage in an Insurance
Company satisfactory to the Chief A4ministrative Officer (CAO). Such policy or
policies shall be issued inthejointrnqnes of the Developer, the Municipality and the
Municipality's Engineer and the form and content shall be subject to fue approval of the
Municipality. The minimum limits of such policies shall be $2,000,000 all inclusive,
but the Municipality shall have the right to set higher amounts. The said insurance
policy shall inc!ude aprovlsion !hat requires the insurance company to provide the
MumClpahtywith thirty (30) days notice of termination of such policy. The policy
shall be in effect for theperiod of this Agreement including the penod guaranteed
maintenance pursuant to Section 5 oftms Agreement. The issuance of such a policy of
insurance shall not be construed as relieving the Developer fromresponsibiIity for other
orlargerclaims,ifany,forwhichhemaybeheldresponsible.
8.6 Legal Notice to Dt'veloper
Any notice required to be given hereunder may be given by registered mail addressed
to theThlveloper at his prindpal pla.::e of business and shall be effective as of the date
of the deposithereofin the PostOm.::e.
8.7 Registration
The Developer .::onsents to the registration of this Agreement upon the title to the Land
both before and afterregtstration of the Plan at the sole discretion of the Municipality
andatthe expense of the Developer.
8.8 Mortgages/Encumbrances
The developer covenants and agrees to obtain and register, at its sole cost and expense,
a postponement from each encumbrancer with a ch:u:ge registered against title to the
Land (or part thereof) so that notice of this agreement shall be registered in priority to
any such charge.
Further, the mortgagee, ifany, agrees that in the event of him assigning or transferring
the mortgage on the lands, the assignment or transfer shall be subject to the terms
hereofin the SllItle manner as if the assignee or transferee had executed this Agreement.
8.9 Requirements for Building Permits
The approval of the Plan by the Murucipality or the acceptance by the Municipality of
the Works shall not be deemed to give any assurance that Municipal building permits,
when applied for will be issued in respect of the Lots or Blocks shown on the Plan.
Notwithstending the foregoing, the Developer agrees that it, or anyone claiming titled
fromitorunderitsauthority,shallnotapplYforanybuildingpermitsforLotsor
Blocks within the Plan nntil all requirements hereinaf!er set out bave been carried out to
the satisfaction of the Municipality. It is agreed that a copy of this Section 8.9 shall be
delivered by the Deve}operto each and every Purchaser of Land within fue Plan and to
each and every Bnilder obtaining a Building Permit for any Lot or Blo~k or part of a
Lot or Block within the Plan and the Developer shall extract a covenant similar to this
covenant from all such Purchasers and Builders. The Municipality shall have the right
to refuse any such application until:
tal Preliminary Acceptance has been granted by the Municipality for Stage I
servicing forthatphaseofthe Silbdivision.
(b) The Developer has provided sufficl~nl documentation to the Municipality's
Engineer confirmmg that electrical distribution and street lighting and the
remaining underground service"S~ telephone, cable t.v., and gas are being
scheduled for instal1ation; and will be completed within sixt61 weeks or the date
ofissuanceofthebuildillgpermit.
18
Ie) ApprovaloftbeMunicipalityhasb~enobtainedfcrrtheconstructionofany
buildings to be erected on Lots or Blocks that maybe listed in Sch~dule "F"
hereto.
(d) A certificate has beeu given by the Municipality's Chief Building Official that
the building location is in compliance with the zoning by-law of the
Municipality.
(e) The SIgns denoting ..Unassumed Roads" have been installed at the entrances to
iheSubdivision.
(f) All dead trees within the limit of the Plan have been removed.
{gJ All street identification signs'requiredbythis Agreement have been installed and
are in place;
(h) Payment to the Municipality in the amount of$2,500.00 as a Works DamagelLot
Grading Compliance Deposit (herein "DamagelLot Grading Deposit") per Lot or
BlockinthePlanofwbichthesumof$100.00isnon-re:fundable.
The balance of the DamagelLot Grading Deposit shall be refundable ill whole or
ill part after the building has been constructed, an Owner's Final Grading
Certificate has been filed Wllh and accepted by Ihe Mumclpality's Chief Building
Offielll! and the required service connections have been made and all damages to
the Works which form the subject matter of this Agreement resulting from house
buildingandlorlandscapingactivitiesonthesubjectLotorBlockhavebeen
repaired to the satlsfaction of the Municipality's Chief Building Official and
Municipality'sWorksSuperintetident.
(i) Withrespecl to repair of damage to the Works, in the event that the Owner fails to
repair the damage to the Works when so instructed by the Municipality's Chief
Building Official or the Municipality's Works Superintendent, the Municipality
may, at its optlon, undenaketherepair of such damage and all costs over and
above the $2,500.00 deposit shallbe charged backtn the Ownerand shall include
a management fee of 15% Oflhe cost of labour and materiaL This shall be a
charge against the Lot or Block focwhich repairs were carried out and shall be
payable forthwith.
0) Payment to the MuniCipality the amount of the current applicable Development
Charge(S) per Lot or Block in the Plan under the Development Charges By-law of
the Municipality, or The Waier and Sewer Contribution tn Capital Policy.
(k) A Certified Building Lot Site Plan has been filed with the Chief Building Offictal
of the Ml.micipalitypursuantto Section 6.4 (b).
(I) The Developer agrees that the preCedingrequirements in this Section 8.9 are in
addition to and not in substitntlon of the requirements of the Ontario Building
Code Act as amended and regulations thereunder with respect to the issuance of
Building Permits.
8.10 Requirements for <Xcupancy
SUbjecttoSeclion8.11herein,nobuildingerecledontheLotsorBJockswithinthe
Plan shall be occupied until a Certificate ofInspectionre: Readiness for Occupancy
bas been issued by the Municipality's Chief Building Official and the said Certificate
shall not be issued unttl:
(e) Preliminary Acceptance has been granted for Stage 2 servicing for the phase of
the Subdivision including the Lot or Block.
(bl The roadway frotnthe emranceofthe Su1xlivisionto and including the lot or
blockofwhichthebuildingisf!par!,hasreceivedthebasecourseasphalt.
19
(c) Theelectricaldistributionplantincludingstreetlightshavebeeninstalledand
approvedbytheUtihty.
(d) The traffic and street signs have been installed and approved by the
MunicipalitysEngineer.
(e) Subject to Section 6.4 tc). the final grading of the Lot or Block is inoonfonnitv
with the overall grading plan or such variances therefrom as have been approved
by the Municipality's ChiefBuil\ling Official pursuwrt to Section 6.4 (c).
(f) The lelephone lines, cable T.V. and gas mains bave been installed and approved
by the Municipality's Engineer.
(gl The Developer agrees thaI thepreceding requirements in this Seclionare in
addition to and not in snbstitution of the requirements of the Ontario Building
Code Act as amended and regulations thereunder with respect to rertificates for
occnpancy.
8.11 Special Build1ng Permits I Model Homes
Pursuant to S8l-1:ion 8.</building permits are not obtainable until certain services are
installed and approved by the Mrnllcipality's Engineer. The Municipality agrees that if
the Developet orOwnerwishesto obtaln a building permit prior to the installation of
s.mrices, as set out in Section 8.9,apermit may be issued provided the Developer or
Owner has executed a No-Occupancy Agreement (Schedule "r') and the Municipality
may require a deposit or LetterofCredit as a guarantee of no -occupancy. In the event
that the Developer or Owner fails to meet all therequirements set out in Section 8.9 or
8.IOforanybuildingpermilthatisissuedpursuanttotheDeveloper'sdeliveryofaNo-
Occupancy Agreement, the DevelOPer hereby acknowledges that the deposit shall be
imrnediarelyforfeitedtotheMunicipality. Such failure to medthe obligations shall
constitute a breach of this Agreement and the Municipality may immediately draw
down any security held under this Agreementto complete any work required orfulftll
any other requirements of Section ::1.9 Or 8.10 for any model home thai was built
pursuanttothisSection8.11.
&.12 Right to Enter into an Agreement
The Developer agrees not to call into question directly or indirectly in any proceedings
whatsoever in law or in equity any administrative tribunal, the right to the Municipality
to enterinto this Agreemoot and to enforce each and everytenn, oovenant and
conditionhereiu coutained and this Agreement maybe pleaded as an estoppel against
the Developer in any suchproceeding8.
The Developer acknowledges that the Municipality is entering into this Agreement and
approving tbe Plan on the express representation of the Developer that it and lls
successors and assigns shall observe and perform all the provisions of this Agreement
and that the Municipality is of the opiuion that the Plan would not be in the public
interest if the Developer, its successors and assigns. the owner or owners from tlme to
time of the land within the Plan were not obligated to observe and perfonn all the
provisIons hereof except to the extent the Mumcipality may lawfully change them.
8.13 Successors and Assigns
The covenants, agreement, conditions.. and undertakings herein contained on the part of
the Developer shall run with the landilnd shall be binding upon it and upon its
successors and assigns as awners and occupiers of the said lands from time to time.
8.14 NotifieationtoPurchaser
The Developer shall in every Agreement of Purchase and Sale or Offer to Purchase
pertaiuing to any Lot or B10ckwithinthe PIannot!:fy each purchaser of all of the
payments to be mad", hythe purchaser 10 the Municipahty pursuant to thIs Agreement
and all oftheprov!sions of this Agreement which shall oontinue in force after the
completion of the sale. Further, the Developershall furnish a list of those services
included in the purchase, specifying those installed and those to be installedatno
additional cost.
20
8.15 Schedul1ng, Progress llud Completion
The Developer shall commence construction of services within eighteen (18) months of
the signing of this Agreement or the registration of the Plan whichever is earlier.
Within eighteen (18) months oithe dlJ.te of commencement of the servicing of my
phase, the Developer sha11 complete the inBtallation of the Stage 1 services. Inany
phase, the top coat of asphalt shall be completed within twenty-four (24) months of
preliminary acceptance of Stage 1 of the services; unless written consent altering this
condition IS rooeived from the MUllIdpal Engineer. Failure to adhere to the above
schedule may result in the Municipality completing the Works in accordance with
Section 3.7 afthis Agreement. lfthe development is phased, the date for
commencement of construction on the balance of the phases may be delayed for up to
five years. Failure to commence construction within the time schedule above may
result in the Municipality declaring this Agreement to be null and void, and the
Municipality may deem the property not to be a Plan of Subdivision.
8.16 No Municipal Liability
This Agreement and the provisions herein do not give the Developer Or any person
acquiring any interest in the land within thePlan (each hereinafter in this clause called
'such person"), any rights against the Municipality or the Municipality's Engineerwith
respect to the failure of the any such person to perform any obligatious under fuis
Agreement or the failure of the Mllnicipality to force such person to perform any
obhgationsunderthis Agreement or any negligeuce of any such person in the
perfonnance offue said obligations.
The only duty and responsibility of the Municipality s Engineer arising out of fuis
Agreement is to the Municipality and thiJ; Agreement. Anywork or services done or
performed by the Municipality's Eilgineer under fuis Agreement do not in any way
create any liability on the part of the Municipality's Engineerto the Developer or any
person acquiring any interest in the landwithin the Plan.
8.17 Assignment
The Developer shall not assign this Agreement without thepriorwntten consent of the
Municipality,which consent may not be unreasonably withheld.
8.18 Conflict
In the event of any conflict between or among the plans and specifications relating to
the construction of the Works, the Munic:ipality's Engineer shall decide which
provisions shall prevail.
8.19 Severability
Ifanyterm, covenant orprovtsion of this Agreement shall be found or declared by a
Court ofcompetentjurisdiclionto be invalid. unenforceable or ultra vires. suchlerm,
convenant or provision shall conclusively deemed to be severable from all other terms,
covenants and provisions ofthisAgreernent and the remainder of this Agreement shall
be and remam in full force and effect.
8.20 Amendment
Without in any way limiting the rights of the Murucipality, the Developer agrees that
the Municipality may, with the consent of the then registered owner of any land within
the Plan. amend this Agreement insofar as it specifically affects such land or any part
thereof.
21
8.21 Further Assurances
The Developer agrees that It shall and will, on the request of the Municipality, make,
do, execute orcause 10 be made, dane.orexeootedall such further and other deeds,acts,
things and assurances to ensure the full implementation of this Agreement and to satisf'y
the intention of the partIes as set out in Ihis Agreement.
8.22 Joint and Several
All terms. covenants, provisions and obligations of the Developer in thIS Agreement
shall bejoint and several.
SECTION 9 - FINANCIAL PROVISIONS
9.1 Development Charges, Drainage and Local Improvement Charges
Development Charges shall be paid in accordance with the current Development
Charges By-law of the Municipality.
The Developeragrees to pay for all arre;rrs Qftaxes outstanding against the property
herein d<lscnoed before the approval of the. said Plan is obtained. The Thlveloper
further undertakes and agrees to pay all taxes levied on the said lands onthebasis and
inaccordancewith assessment and collector sroll entries until such time as the lands
herein being subdivided have beenassessed and entered 011 the Collector's Roll
accordmg to the Registered Plan.
Before the Plan is approved the Developer agrees to commute and pay all charges made
with respect to the Drainage Act, the Local Improvement Act, and the Municipal Act,
including but not limited to charges or rates outstanding m respect of the Lands under
any sewer rate andIorwaterrate by-law which are assessed against theproperty on the
Plan. Before the Plan is approved the Developer agrees to commute and pay the
Municipality's share of any charges made under the said Drainage Act, the said Local
Improvement Act and the said Municipal Actpresently servicing this property and
assessed against it.
9.2 Securities
Prior to registering this Agreement, the Developer shall deposit WIth the Municipality
10 cover the faithful perforrnance of the contract for the installation of the said services
and the payment of all obligations and contingencies arising thereunder the following
securities:
I'}
Cash iu the amount of One Hundred Percent (100%) of the estimated cost of the
said all works as set out in Schedule ~E~ and as approved by the Municipahty's
Engineer and Municipal Council; or
~}
An irrevocable Letter of Credit from a chartered bank, issued in fcmnand content
satisfactory to the Municipality s SolicilOr, in the amount of One Hundred
Percent (100%) ofthe estimated cost ofall works as set out in Schedule 'E~and
asapprovedbytheMunicipalitysEngineeror
(0)
Some combination of cash and Letter oferedit, totaling 100% of the Schedule
'E"estimate.
<dl
Prior to depositing the securities, the Deve!oper's Engineer shall submit an
estimate of the cost of the Works 10 the Municipality's Engineer for approval.
WhenthecostestimatehasbeenapproveditwillbesetoulinSchedule~E"of
this Agreement and will beC'Om~ the basis for the limits of these securities.
22
t e) All Letters of Credit shall be for a minimum guaranteed period of one ( I) year or
such longer time as theMunicipality may dectde. Alll.etters of Credit referred
to in this Section 9.2 shall contaiilthe following clause:
;'11 is <2 condition of the utter afCredit that it shall be deemed to be
automatically extlmdedwithrmf amendmentfrom year to war from the present or
an)' fUture t?Xpiration datt? thereOf unless a/least thirty (30) days prwr to the
present or any future ""piralia" date, we notify you in wriling by registered mail
that we elect}U)t tQ c(>>l$ider this Letter afCredit to be renewable for any
additionalperiod."
(f) Unless each and rwery Letter ofCredil is renewed as noted above, the
Municipality shall have the abso\ute right to refuse to issue building permits and
to prohibit occupancy ufhomes, whether partially arfully completed, from the
said date thirty (30) days prior to the expiration of that Letter of Credit.
9.3 ReductiODOfSecu.rities
An application for the reduction of the security on deposil with the Munidpality
pursuant to Section 9.2 herein maybe-made no earlier than thirty (30) days after the
commen~ement of construction of the Works and every thirty (30) clear days thereafter.
(a) To obtain a reduction in security the Developer shall file with the Municipality's
Engineer a written application in accordance with Schedule T'attachedhereto.
(b) The application shall include written confinnation fromthe Developer's
Engineer:
. describing the Works constructed as at the date of the application and a
calculation of the cost thereof.
. confmning that the Wor~ have been installed by the Developer with full
time supervision of the Developer s Engineer and in accordance with the
requirements of this Agreem.mt and schedules hereto.
. describing the Works reIllRh,ingto be completed as at the date of the
application and a calculation of the estimated cost thereof.
(c 1 The value of the reduction shall be determined by the Municipality's Engineer
who shall give a certifiCale to the CAO and the Developerconfinningthe amount
of the reduction of the security and the amount of the security remaining on
deposit with the Municipality.
Id) Thevalue of the reduction shall be based upon the value of the Works remaining
to be completed by the Developer plus ten percent (10%) of the value of the
Works completed to the date of the application.
(e) Subjecttoanyoutstandingdeficienciesorcontingencies,theMunicipality
throughout the maint.enance period shall hold as security the greater often
percerrt(JO%) oftheesdmate of the cost of the Works as set out in Schedule "E"
or twenty thousand dollars ($20,000.00).
9.4 Statutory Dedaration of Accounts Pjljd
The Developer agrees lhat upon applying for a discharge of securities or for a
Certificate ofPrelimirnuy Acceptance for the services. he shall supply the Municipality
with a Statutory Declaration lhatall accounts for work andmaterials forsaidservices
have been paid except normal guarantee holdbacks and that there are no claims for liens
or othetWise in connectton with such work done ormalerials supplied for or on behalf
of the Developer in connectionwilh the Subdivision.
23
9.5 The Construction Lien Act, R.S.O. 1990 e.. C.30
The Developer agrees thai it will holdback in its payments to any Contractor who may
constructtbe services, such sums as are provided in accordance with the Construction
Lien Act, R.S.O. 1990, c. C.30, and will otherwise indemnify and save harmless the
Municipality against any claims, actions or demands for construction liens or otheIW:ise
in .::onnection willi the works and all costs in connection therewith, and on the demands
of the Municipality's Solicitor 'Will furthwith take such steps to immediar.ely discharge
all Liens upon the seIVices.
Notwithstanding anything to the contrary contained in this Agreement, the Developer
hereby agrees tbat the perfecting of any liens pursuant to the said Construction Lien
Act, with respect to the land descnoed in Schedule '"A" 3ttached hereto, shall constitute
a default by the Developer oftha terms of this Agreement and shall entitle the
Municipality to draw on any or all of the seuuityreferredto in Section 9.2 of this
Agreement and to utilize said draw to make payment into Court of the holdback
together with COSIS.
9.6 Partial Release
Upon completion ofall the requirements of this Agreement, the Municipality WlIl
execute a parual release of this Agreement, which partial release shall be in the form
attached hereto as Schedule "K" The completion and registration ofslK'h partial
release shall constitute a full and final release of the obligations of the Developer, with
the exceptionoflot gradingrequiremenls included in Section 6 of this Agreernent, as
establishedhereunderwithrespecttothelotnamedtherein.
Nutwithstanding the foregoing, the CAO shallnotbe required to execute a parttal
release until the various services have been completed in accordance willi the rerms of
lliis Agreement and theplans and specifications provided for herein.
SECTION 10 - SPECIAL PROVISIONS
10.1 The Developer and the Mmticipality agree tbatthe provisions set forth in the attached
Schedule "M" form an integral part of this Agreement.
24
SECTIONl1~SIGNATURES
1HIS AGREEMENT shall be binding upon and inure to the benefit of the parties hereto
and their respective heirs, executors, administrators, SIl=Ors and assigns.
IN WITNESS WHEREOF the parties hereto have exeru.ted this Agreement
SIGNED, SEALED AND DELIVERED this 19'" day of September A.D. 2007
(1~79OntariOInc.
~ fili-
(Dale alden
(YWe have authority to bind the Corporation
(
(TIlE CORPORATION of THE MUNICIPALITY OF
( KIN INE
(
(
(Mayor
~\ '-- )..~~'"":j'I~?>.""-(/
(Chief Administrative Officer
{We have authority to bind the Corporation
Developer's Address: clo Dale Walden, P.O. Box 351,Kiucardine, ON N2Z2Y8
Developer's TelephDne: 519-395-3342
Developer's Facsimile; 519-395-3374
25
SCHEDULE "An OF AGREEMENT
NOTE: It is understClod i'lIId agreed that this Schedule fOI1IlS part ofllie Municipality's
"<",,,,,,,,.
DESCRIPTION OF LANDS BEING SUBDIVIDED
Part of LOIs A, B and C, Concession A, Geographic Township of Kincardine, Municipality of
Kincardine, County of Bruce.
(Note: This Agreement is for Lots 1-37 and associllted blocks,part of File 41T-2007.02.22).
26
SCHEDULE"B"OFAGREEMENT
NOTE: It is understood and agreed that this Schedule forms pan of the Municipality's
Agre_c
PLAN OF SUBDIVISION
,
<
,
------,.---
l=""" ="",""'-
i ",:;0::',-
l,__.~
_._-~._-----
'---'-~'-"
____M___~
''''.~''"
6=-
\
_J"\
-=~-l
,
'-."
,
,%-'..1
..i--'--'';~o.'-'~'-1 !
fiI" ,I=,j
I', "-,,
"" ~ ,; '';
'."
.",..,.;,.!,
(, i' ',; i:
, . '~'kl!
I"', .._~--~ '~l'
.i',
i' ......- h,.,_' .:(j:f
f:'r, }" !!~';-.. -:",Ii
- ~ - _ ',ii.- ,
",' -.:. ,;.~. r, 'I,';' ..~,,,,,...,~,,_....,,,,,,,,,,,.
if. f ,. <, . ;!="'--~--"-i~ ,- ." 'l
''P." I': f ~ \...:'~' -J _, ;.) "
':'f.~ ~,. - ~, :\; ,
" ~} ,;,t... ,...' "k c_ ,_ ,)._. '
ij- }.;....!' L,;"__,f,:"T~;'_"":'""i-.. '-', i~
f,"'.:;;~~.;-/ j., .j.! ('';"' e)'I'! \~
',,, ,. '. t' "', "'.-
't":~f:"; \"". ''-'''..-.r,- .- II '-'#.
- -'..,:_:-~,-."" :....."".
c,~ f1"- '"'i""""";'!' 'R', -t"j, J:
("~ .-tc-:"'-;_!,":, '-~:-'-'-'-"->>~,'-.,';"-r,'!-i ii:: ~.'
,-H'1-!"-HJ -1-1'11'1 !'~j",i'"
......,.",- "'.' '",
,~4<-.L._,_ ""'-~,____ ~ '~_~.""'""_"- ~ __'<-___0 ~
'-
-"'-~-~.~
--
,-.-
,
. "=,--"~-'-'~ '.
~""e~~ -,,-
,
~,~._--
,
'~'- , ,
u... , ,
,"'..,."''''''"
--,~~-
if---
---
--_..
==-="
,- -,
;;:;,. - ,:;;,:;;
-
._n__._
----.-.-
~. .'
, "
~ .
_.
-~+-~..._-
-- --- -
-- .
-;".-~~-
--
--
=h=~
.-
L~nFIEllJ
E'TAT'"
5UBlJIViSlO
- .. -
.,
~
,
27
SCHEDULE "C" OF AGREEMENT
NOTE: It is nnderstood and agreed thatthis Schedule forms part of the Municipality s
Agreement.
1.0 GENERAL
MUNICIPAL SERVICING STANDARDS
Service Layout Plan
A copy ofllie Genera! Plan shall be submitted to the Municipality identifying the
proposed locations of Bell Cables, electrical servicing, gas mains, co-axial television
cables as well as watermains, storm sewers and sanitary sewers. All locations mustbe
established and resolved by the Developer's Engineer in conjunction willi the Utility
companies and following the locations shown on the Municipality's Typical Cross-
Section.
2.0 PLANS AND DRAWING REQUIREMENTS
Plan and profile drawings must be prepared ina digital format, which is compatible with
AutoCAD Release 14, and on velum or mylar, fOf all new streets within the Municipality.
Thesedigitizedfi1esanddrawin~andalsodigitizedfi1esanddrawingsshowingdetails
of special stmctures, etc., shall be preparedby a Professional Engineerandturned over to
the Municipality as apermanentrecordprior 10 the acceptance of services required to be
provided by the developer.
The following standards shall be adhered to m preparation of these drawings:
(a) All profiles must be shown to the geodetic datum which is noted on each
drawings.
(b) In general,East-West streets shall have zero I.'hainage at their Westerly limits and
North-South streets shall bave zero chainage at their Sontherly limits. Chainages
on Plan and Profile shall increase from left to right.
(e) Drawings shall be of a consistent size - 594 mm x 841 mtn.
(d)
('J
(0
(gJ
Scales shall be as follows for drawings:-
General Layout Plan Scale Ratio
PIan_ProfiffiDmwings HorimnW
Vertical
or Horizontal
Vertical
Ratios shall be shown on all draWIngs.
1:1000
1:250
1:50
1:500
1:100
When the planmnstbe broken hocanse of curvature, etc., the prufile shall be
brokenaswell,sothat,insofaraspossible,chainagepoints inpian and profile
wjll coincide vertically.
The beginnings and ends ofcurves must be shown on theplanandprofile with
the radius of curvature shown on the plan. Chainages of points of curvature shall
be calculated.
The chainage and names of intersecting streets shall be shown in plan and profile.
The drawings shall show clearly the proposed profiles, road widths and cross-
secllons, ditches, ditch gradients, eurb gradients ifdii'ferent from the proposed
servIces, north sign and limits of the proposed work The plan shall show any
required off-street drainage and separate profiles sha1lbe prepared for drainage
easements. All detail for intersecting streets including grades must be shown for
adistauceof50metresfromtheintersectionoftheintersectingstreet. AIIstreet
lines. for drainage or services, shall be shown and all easements.
28
(h) The Municipality shall be named-in the title block which shall be placed in the
lower right comer.
(i) On completion ofihe work, and prior to acceptance oflhe services, the drawings
shall be completed "As Rec:orded"and dated befure tuming over to the
Municipality. TheMunicipality shall be consulted as to the manner of showing
infonnarion not set out in these requirements. The Developer's Engineer shall
add his Professional Engineer s seal to all final drawings.
3.0 ROADS
3.1 General
All roadways shall be serviced by storm sewers and concrete curb and gutter. Road
allowances shall be a minimum of 20 metres wide. The edge of the roadway paved
surface shall have a minimum radius of9 IThltres at intersection. A.::cess roads not owned
by the Municipality, leading to the area ofthe development, shall be maintained to a
standard equal to the standards for roadways within the development. On all streets,
horizontal and vertical sight distsnces and vertical CUIVes shall meel Minisll)l of
Transportation (M.T.G.) requirements.
Street allowances on cul-de-sacs are to have a minimum radius of 20 metres. Edge of
pavement radius on cul-de-sacs are to bea minimum of 13 metres.
Minimum road asphalt width shall be 8Jilnetres. The finished roadways shall have a
cIOssfall of2% from the centerline to' each curb line, and the boulevards shall have a
finished crossfall ofa minimum of2% and a maximum of8% from the top of curb to
back of boulevard draininglowards the curb.
3.2 Clearing and Gfubbing
Trees shall be removed so that the speclfications for sight distances, grading, ditching.
etc., may be met. All stumps, logs, brush, boulders, debris, etc. shall be removed from
the entire street allowance. Unless notecl othenvise, all healthy trees nOI obstructlng
visibility or msta\lation of services shall be preserved. The MunicipalEngineer may give
special permission to leave trees on the street allowance, providing thaI they are situawd
more than 1.5 metres behind the curb.
3.3 Gn.ding
A 2 metre boulevard area behind the curbs shall be graded at a minimum of2% towards
the curbs. The area from the edge of the toad boulevard to the street line shall be graded
with a side slope not exceeding a slope of 3 metres horizontal to 1 metre vertical to meet
the original ground. All side sloped ditcbes andboulevardsto the street line shall be
protected with nursery sod over aminiml\ffi depth oflOO nun of topsoil.
3.4 Road Construction
All road construction shall conform to applicable standards ofthe Ontario Provincial
Standard Specifications (OPSS) and the Ontario ProVinCial Standard Drawings (OPSD).
The granular roadbase shall consist of Ii: bottom course of 300 nun minimum depth
consolidated Granular "B" full width aciOss the roadway and a top course of 150 rom of
Granular 'A" fun width between concrete curbs. The granular matenals shall he spread
in layers of 150 mmmaximum compacted depths, and each layer shall be thoroughly
compacted. No granular base ofsurfuce'material shall be placed until the grade on whiCh
it is to be laidhasbeen inspecled and approved by the Municipal Engineer. Duringand
between construction seasons, the granuiarbase shall be maintained suitabJe for vehicle
and pedestrian traffic, including dnst control by calcium chloride and renewed ifrequired
to the satisfaction of the Municipal Engineer.
Rood subdnilns shall be provided in accordance with OPSS 405.05. The subdrain shall
inclndef1lterwrlip (non-woven type) Class I andF.O.S.0f110-IOO.
29
3.5 Roadway Surface Asphalt
As soon as the granular base has been completed, it shall be thoroughly compacted and
shaped and Ihe base course of asphalt pJaced. The base course shall consist of 50 mm
miuimum thickness ofHL-4 Base Course Asphalt. The surface coot of asphalt may be
placed upon the approval of the Municipal Engineer whtch shall not be given for at least
one year from the date of placement of the base course of asphalt or until 50 percent of
the houses have been constructed. The surface course asphalt shall consist of 40 nun
minimwn thickness of HL-3 Surface Course Asphalt. Asphalt work shall conform in all
respectstoOPSS310.
3.6 Curbs
Concrete curb and gutter, of cross-section approved by the Municipal Engineer, shall be
provided along all edges of paved roadway surface. Tenninations at the limits of the
subdtvision shall be eitherjoinedto existing concrete curbs orrounded to reduce hazard
to traffic. Construction shall conform t:o:OP$S 353.
3.1 Accessibility
As part of construction of any concrete curb and gutter, sidewalks or other surfuce
strucrures, the Developer will be responSible for construction inaccordance with the
Municipality's current accessibility standards to provide full access wbere possible. to all
individualsintbeconununity.
3.8 Driveway Aprons
The Developerwill provide at eacb driveway, orwill cause to be provided by subsequent
Owners, a driveway apron from the hack of the curb to the face of the sidewalk or where
tbere is no sidewalk, to the liInitofthe property line, This driveway apron should be hard
surfaeed with either 50 rom of asphalt pavement or a minimum of 100 nun of concrete
pavement over the granular base, consisting of a minimum of 100 mm of granular "A"
and 200 mm ofgranuiar "B~ Alternatives to these surfaces may be considered subject to
the approval of the Municipality.
3.9 ThrningCircles
Where ()Q)1struction is phased, the Municipality may require the installation of temporary
turning circles. Theseturning circles will be constructed in accordance with the
requirements for cul-de-sacs in Section 3.1 of this Scbedule. Elsewhere in the Agreement
are provisions for conveyance of blocks forthe constmction of said circles.
4.0 STORM DRAlNAGElSTORMWATE;R MANAGEMENT
4.1 Approval of Design and Plans
Stonnsewerssballbeprovidedtosillvethewboleofthesubdivision. Drawings shall
consist ofan overall plan, a plan and profile ofeacb stonn sewer, drawn to the same scale
as the roads, pipe bedding, manholes, and other appurtenances. Design of the proposed
works mustbe submitted to the Municipal Engineer and applicable government agencies
for approval. Plaosoftheentiresyslen1~ha11besllbmittedtotheMinistryofthe
Environment for approval. Approval for construction will not be given until the
Certificate of Approval for the sewers bas been received frotn the.Ministry of the
Envrronment and all other applicable govermnent agency approvals bas been received.
30
4.2 Stormwater Management Report
A Stormwater Management Report setting out the existing and proposed drainage pattern
together with a Lot Grading Plan and an Erosion and Sediment Control Plan shall be
submitted to and approved by the Municipal Engineer, the local Conservation Authority
and the Ministry oftheEnviromnent.
The stormwatermanagementrequiremenrs within the Municipality shall be those of the
local ConservationAllthority or as jistedbelow. The general requirements are as follows:
. Quality and quantity control- as diclated by the local Conservation Authority and
MOE requirements in accordance with the MOE "Stonnwater Management Practices
Planning and Design Manual" or the J;Ilost recent version thereof Quantitycontrol
shall restrict post-development runoff flows to pre-development flows between the 5
and 100 year events.
. The design storm for the minor systems shall be the 5 year storm for local storm
sewersandthel0yearstormfor~fucilities.
. Sediment and <lTOsion control measures associated with the slonnwater management
mquirements shall be identified on the drawings for works to be mcluded during the
construction and for permanent measures.
4.3 ConnectioDtoMuuicipalSystem
The storm sewers shall be connected to the Municipal Slorm sewer system or discharged
to a naturol watercourse as approved by the Municipality and the Ministry of the
Environment.
4A Design Criteda
The stormwater management system shall be designed by using MIDUSS version 4.72.1
or an alternate approved hydrologic model. The Developer's Engineer shall consult the
CunservationAuthority as to the appropriate storm distribution and durallon to be used.
The Developer's Engineer shall advise the Municipal engineer in writing as 10 the
Authonty's requirements. The minor system(storm sewer) shall be designed to convey
the 5 year design storm, while the major system shall be designed 10 convey the 100 year
design storm. Post-development nmoff flows shall be controlled to pre-development
levels for rainfall events with return periods between 5 and 100 years. The design of the
stormwater management system shall be in accordance with the newest version of the
"Slormwater Management Practices. Planning and Design Manual", as prepared by the
Ministry of the Environment.
4.5 L:H-ation
The storm sewer shall be located within the street, with lateral connections to catch basins
located alongthe gntter lines.
4.6 Sewer Pipe Material
Sewer pipe material shall he Concrete Pipe, or approved alternate, complete with rnbber
gasket connections Class C14ES or reinforced concrete pipe of the class required for the
depth of cover. The minimum size, including catch basin leads, shaJI be 300 mm. The
Municipality may require a larger storm sewer size on parts of the subdivision than
reqwred for the subdivision aIone.
31
4.7 Storm Sewer Construetlon
Stonn sewer construction and pipe bedding shall conform to the requirements of the
Ontario Provincial Staudard Specifications for sewerconstruclion. Pipes shall be bedded
in approved granular materials.
Catch basin leads shall be connected to the main sewer with a manhole except where the
main sewer size exceeds 450 nun diameter, in which case the lead can be connected
directly to the main sewer using a faclorymanufactured "Tee~
4.8 Manholes and Catch Basins
Concrete manholes shall be provided at all chBnges in direction of the sewer and at all
streetint=ctions, but no further apartthan 120 ill. Mllllholes shall be 1200 mm
diameter or larger, conforming to apSD Series 700. Benching shaH be provided in all
manholes_ Catch basin manholes shall contain a sump or minimum depfu of 300 mm
below lowest invert on sewers up to and including 450 mm diameter.
Frames and covers shall be OPSD 401.01 Type A, or approved equal, set on Dot less than
three (3) layers nor more tban six (6) layers of brick which shall be parged on the outsid e
face. .
Catch basins shall he provided on both sides of the street at all low areas but no further
apart than 90 m. Catch basins for depth up to 2 m from ground level to invert shall be
6()() nun square concrete conforming to OPSD 705.01. For greater depths, catch basins-
manholes shall be used confonning to OPSD 701.03.
4.9 Private Drain Connections
Private main connections to the stonn sewers shall be provided for each residential unit.
A 100 IIUll diamet.er.::onnection suitable for receiYingpumped sump flow from footing
drains will be placed at a depth of 1.4 rnetJ:es at the property line on each 101.
5.0 SANITARY SEWERS
5.1 Approval of PI aDS
Plans of the entire system shall be submitted to the Ministly of the Environmerrt and the
Municipal Engineer for approval. This submission shall COl1Jlist of an overnll plan, aplan
and profile of each main sewer drawn to the same scale as the roads, together with typical
details ofhonse service connectious, pipebellrling manhole covers, all special bends and
connections and oilier appurtenan.::es. Approval for constructlon will not be given until
the Certificate of Approval for both Smiters and sewage treatment facilities has been
rece1Ved from the Ministty of the Environment.
5.2 Location
The main sewers shall be located alongthe centre of the street allowance. House
.::onnections shall terminate at the properw line at the centre of each lot.
5.3 Material
Main sewers shall be P.V.C. or approved alternate. House connections shall be P.V.C. or
approved alternate. Alljoints shall be of the mbbergaskettype as approved by the
Municipal Engineer. Approved caps shall be provided for service lateral terminations.
5A Size
The minimum size for main sewers shall be 200 nun diameter. House connections shall
be a minimum of125 mm in diameter. For multiple dwelling, industrial or commercial
buildings, the service connectious shall be sized to aooommodatethe flow
32
5.5 Sanitary Sewer Construction
Sewer construction and pipe bedding, shall conform to the requirements ofOPSS 410 for
sewer construction. A minimum 2.0 metre depth of COver shall be provided over all
s!ll1itarysewersandservicelaterals.
5.6 HouseConnecti.ons
Plan locations and invert elevations, for all house connections at the street line, shall be
shown on the drawings Minimum fall on house connections shall be 2%: maximum 8%.
When: the depth of sewer is excessive, a riser may be used uver the main sewers. Shop
manufactured "Tee" connections shall be used for house connections to the main sewer.
A cap ofapprovedrnanufilcture shall be installed on each service lateral termination at
the street line and mad" watertight. The ends of all services shall be marked by a 50 nun
x 100 mm wood post extending from the service to 300 nun above the surface of the
ground and the top section painted fluorescent green. Connections to manhole:s shall
enter the manhole no bigher than 0.5 m above the lowest invert, except as otherwise
approved by the Municipal Engineer.
5.7 MaDholes
Concrete manhoks shall be provided at all changes in direction ofllie sewer and at all
street intersections, but no finther apart than 120 m. Manholes shall be 1200 mm dia.
Conforming to OPSD 701.010. Benching shall be provided in all manholes.
5.8 Testing and Flushing of Sewers
The complete so:wer system, including house connections, shall be tested and flushed in
accordance with OPSS 410. including tlwrequirement for camera inspections. The
Developer shall arrange the tests for sections of sewtll" between manholes and shall inform
the Municipal Engineerwhen a section'is'on test and ready for inspection. Any sections
of sewer which fail to meet the requirements of this section shall be repaired and retested.
5.9 Completion and Acceptance
The complete sewage collection system installation mustbe approved by the Municipal
Engineer prior to the issuance ofbnildingpermits for the subdivision.
6.0 WATERMAINS
6.1 Approval of Plans
Plans of the entIre system shall be subnritted to the Ministry of the Environment and the
Municipal Engineer for approval. This submission shall consist of an overall plan, a plan
and profile of each wmermain drawn to the Satrul sca!e as the roads. togetberwithtypical
details of house service connections, pipe bedding and other appurtenances. Approvalfor
construction will not be given until the Certificate of Approval for the waterrnain system
has been receIVed from the Ministry of the Environment.
6.2 Locations
Watermain: The watermain shall typically be installed within the boulevard of the
street, in accordance with the Municipality's Typical Cross-Section.
Service Lines: In general, house serviCeS shall not be installed in driveways. Where the
driveway location is unknown at the time ofwatermain construction,
service connections shalLtenninate at the property line al the centre of
each lot.
Main Valves: To be located at the extension of property line. where the valve is being
installed at intersectinns.
33
Curb Stops: To be provided for each service connection and to he located at the lot
line
6.3 Co....ectiontotheMnniclpalSystem
In general, the watermains shall be looped to existing municipal systems.
6.4 Material and Size
Watennain:
Gate Valves
and Boxes:
Fittings:
Hydrants:
Services:
Watennain material shall be Polyvinyl Chloride PVC-C-900 Class 150
(DR-I8). Pipejoints shall be bell and spigot vvith rubber gaskets.
Valves shall be resilient seated gate valves. Main line valves to be MJ
type with standard operating nut. Hydrant valves to be MJ to MJ gate
valve with standard Opcrating nut.
All valves to be supplied with "0. ring packing for water use and open
counter-clockwise.
Valve boxes sball be Canada Valve screw type with No.6 base.
Tapping valves and sleeves must meet WIth approval of the Operating
Authority.
Resilient-seated gate valves shall be in accordance with AWWA C509
All fittings shall be ductile iron cement mortar lined mechanical joint
(MJ) type with adaptoTS to suit othermalerials, where necessary. All
fittingsmustbesuitablythrusthlockedusingconcretethrustblockIngas
perOPSDI103.010orl103.0Z0. Apolyethylenebarriershallbeusedto
prevent a bond between the fitting and the concrete.
Ductile iron fittings Sha11be in acrordance with AWWA CliO and the
rubber-gasket joints for ductile iron fittings shall be in accordance with
AWWAClll,presm'r'ating1035kPa.
Fire hydrants shall be the Mueller Canada Valve New Century type or
approved McAvity equivalent. Hydrant specifications as follows:
. 2_64nunhoseconnections
. Bpumperconnection
. Hydrantsshallop('nc<)uuter-cloekwise
. Colour shall be RED
. Operatingnutshallbt:standard
. Hydrant length shall.be suchthat the bottom of the upper barrel shall
be 100 nun above finished grade
. Bury depth 1.7 m.
Dry-barrel fire hydrants shall be in accordance with AWWA C502.
Min. 19 mm, Max, 50 mm
Corporation stops - Mueller, C.C. thread inlet! compressionjoint
outlet.
CurbStop Mueller,compressionjointinletlcompressionjointoutlet
or approved equivalent.
Pipe - to be 19 nun Type "K" copper tobing.
Service Boxes Model No. D-I by Concord-Clow or Mueller
equivalent. Service box and stem (IA m to 1.7 m) with 25 mm dia.
steel upper section. Box lids shall be regular ribbed Wlthbrass
pentagon plus c1w standard stationary rod.
Service saddles-M(ldel No, 2616 by Robllr Industries Inc., stainless
steel,doubleboJted;bi"oadband.
34
Underground service line valves and fittings shall be m accordance with
AWWA C800.
Model numbers shall be stamped on all valves and materials.
Anodes: 5.5 kg; zinc castirigWith a galvanized steel core, packaged in a cardboard
or cloth bag of minimum diameter of 1 00 nnn. Gypsumlbentomte backfill
IIlllterial (electrical resistiVity <50 ohm em wet). Insulated copper wire
brazed to core wire.
Tracer Wire: All PVC watermain to be provided with a No. Ion strand copper cable
baving TWH insulation.
6.5 WatermainCoDStruction
All watermain and appurtenances to be installed, bedded andbackfilled in accordance
with current Ontario Provincial Standard Specifications and to the satisfuctionoftlw
Municipality.
Minimum 1.7 mall.<: depth ofoover over all mains and services.
Mam valves and hydrant sets shall. generally, be located at a IllilXimum spacing of200
metres and 120 metres, respectively.
At main intersections, a main valve shall be provided at each dlrection from the
intersection, less one.
Zinc anodes to be supplied arnl installed on services.
6.6 Flushing. Testing and Disinfection
All watermain shall be tested, flushed, swabbed and disinfected. Such procedures shall
be in accordance with OPSS 701 forpressure testing and A WWA C651-99 for
disinfection and connection to the waterworks system. The Developer shall inform the
Municipal Engineffi" when the watermain is to be tested and disinfected. Bacteriological
testing will be completed by the municipal operating authority. The Developer will be
billed for any testing orretesting required. Arryfailure of the testing and disinfecting
shalJ require the Developer to reflush, retest andIor redisinfectthe watermain until the
watennainhas met the requirements of the Ontario Provincial Standard Specifications
andtheMOE,to the satisfaction of the Municipality.
6.7 Completion and Acceptance
The complete water distribution systeril installation must be approved by the Municipality
prior to the issuance of building permits for the subdivision.
7.0 SIDEWALKS
A 15 metre sidewalk shall be constructed on one side of each street within the
developnrent. Sidewalks sha11have a r:n;nlm1l1ll depth of 125 mmand shall be bedded in
granu!ar in accordance with the current OPS standard details.
35
8.0 UTILITIES AND STREET LIGHTING
8.1 Telephone
Telephone service shall be underground and shall be installed by 8.M.T.S. or Hurontel.
Tbe Developer must bear the cost of any surcharges for underground installation made by
the Utility and must gram 1he Utility any easements fortheir services.
8.2 Electrical
Underground electrical installation shall be comp1etedto the satisfaction of the local
powersupplierb:tSedontheirmoslciureirtspe6ification.
8.3 Cable T.V.
D.wclopers shall arrange to have Cable T.V. installation completed by the local supplier.
8.4 StrcetLighting
The minimum standard for street lighting shall be 100 watt High Pressure Sodium Lamps
set on 9 metre poJes. or as directed by the Municipality. Each light mustbe controlled by
a dusk to dawn photo-electric celL Power feed shall be completely underground. The
lights shall generally be placed to the outside of curved roads. The maximum allowable
spacing along the street between the lights shall be 50metresb"utmaybeincreased,atthe
Municipality's direction, to a maximum of75 metres (in special instances). The poles
must be installed at the location as shown on the Municipality's Typical Cross-Section.
Particular care shall be taken to adequately illuminate the intersections and cui de sacs.
9.0 LOT GRADING
9.1 House Lot Gnuling
Generaliy, all luts shall be excavnted or filled so thatthe whole of the lot area from the
street line to a line at least 3 metres beyond the rear of the building shall have an
elevation not less than 0.5 metres or more than 2 metres higher th!lll the finished crown of
the road opposite the centre ofthe lot. In situations where the siope of the land justifies
different requirements, the Municipai Engineermay permit variations of the above. A
pi:m showing proposed lot grades and house floor ievels shall be subrmtted to the
Municipal Engineer fur his approval, and the Engineer retains the right to amend any of
the grades proposed if the Engineer considers a particular situation so warrants.
10.0 LANDSCAPING
Boulevards along each street shall be topped with a minimum of 100 mm oftopsoil.
Seeding shall be completed in all boulevard areas.
A tree shall be planted in theboulevw:d iil front of each lot within 1 YeM of the date of
completion of the Stage 2 services. Trees shall be 60-70 nun diameter measured 500 nun
above the ground. Allu-eesshallbeNo.lnurserystock. The type of trees shall be
approved by the Municipality. These shall be staked to Municipal specifications. Trees
shall be watered at the time of planting and every two weeks thereafter and me Developer
shall warrant trees for a period of one year from the date of planting. Planting shall be
iimiledtothespringandfa1lseaso~.
36
11.0 EROSION CONTROL
During constmction the Developer shall ensure that surface rnnofffromtbe lots and
blocks as well as the roadways is protected fromerosion by the use ohill fences, straw
bales and other measures designed to minimize such erosiOll. Temporary outlets at
culverts or calch basins shall be cbecked to prevent silts from entering into stonn sewers
or water courses. Such erosion control measures shall be shown on the drawings for
approval by the Municipal Engineer and the Conservation Allthority.
12.0 WALKWAY
All walkways shown on the plan ohllbdivision shall be constrnct<:d by the Developer.
Walkways shall be constructed ofa 150 mm rninimum depth ofGranular"K ona
properlyconstrudedfoundationandshallbepavedwithaconcretesidewalktoa
minimum width of1.5 metres and aminimurn depth of 125 mm.
A standard 1.5 mhigh cbain link fence shall be placed along both sides oftheriglrt-of-
way with posts placed at each end to prevent vehicular traffic from using the walkway.
13.0 PARKLAND IMPROVEMENTS
The area ofland deeded to the Municipality for Public purposes, other than highways,
sball be carefu1ly graded, care heing taken to preserve any trees. Thewholeareasballbe
top dressed with a minimum of 100 mIll of topsoil and shall be seeded with approved
lawn seed mix (OPSS 572).
The MunicipaJity may ask and provide details within this agreerru:nt for additional
Parldandimproverru:ntsasmightbewarrarrted.
14.0 TRAme AND STREET SIGNS
14.1 Proposed street names shall be subject to the approval of the Municipality
14.2 Street Name Signs and House Numbering
At each intersection there shall b~ erected an approved double unit street name Sign. The
signsandpostswillbeprovidedbytheMunicipalityattheDevelopersexpense.
14.3 Traffic Signs
Traffic signs and posts W111 be provided by the MunicipaJity at the Developer's expoose,
following the passing ofaby-Iaw for their installation.
14.4 GuidePosts
On Fills higher than 2 metres, timb:erguide posts or guard rails shall be installed
conforming to OPSS and OPSD Standards.
15.0 PAYMENT TO SUBDIVIDERS
The Municipality sha11 notbe liable for any costs arising out of the conSlrUction of
servicesexceptunderthefollowingconditiollS.
Where a storm sewer is largerthan required. the Municipality may pay the
difference in cost for supplying the largersizepipe and any additional manholes
required for completion of the system.
"
37
b) When a samtary sewer in excess of250 mm diameter is required, for lands outside
the subdivision, the Municipality may pay the difference in !.'-OS! for the supply of
the larger size pipe.
c) When a watermain in excess of200 mm diameter is required, for lands outside the
subdivision, the Municipality may pay the difference in cost for the supply of the
larger size pipe and fittings.
16.0 TYPICAL ROAD CROSS SECTION
A typicnl mban road cross se-.-'tion is attached.
iSollliis@
lIOIlI'I-I'IPdlt.NOIS1A!11~O!l.1Yl1
'----'0"
~l8JlU'PlIMlllGO'1
BUDAr.IlI'111O\1UagPU811OIP'S
IIDfS\IIIpqnSUlKlm....wOilllr.lldAJ.
lJUJpJlt:)Ul)l
,IOAIIl8dlOlunlll
'^' ,,"", ~ '''' 'O'~',H
,."0"']=("'",,,,,,.
"
00
M
"
0""'0')
"'''~'
,0
<;c,
CO
"
(o""n"",
"""").1\"'\3""
'0""" 0' "",n,
,,,,,",,,.,.
to",.'Hl"""
l
9o"t
.",.,-,..".~.~.~
]NI(W\f?.N]?1~
N\Illl3G"I>'OlWIl)3I.<:alAlla;_"""'III<lJ.""IS3OHOllOlllll.SHo:>!llavOll'S
"Nn.u"""""'"~""'".OJ.S3lllIII~~SIl1V1\\"T1I' ~
....1..'.1lW.-
1l1~O'I^,"llIl""""D"",..,'.."".,-mrm-
...,~ n 0IIll<~ - ~lUIM "C>l S""" OIlIESO"" "".. '.
"<l1e<1..... .,..,""" ~"""... OJ. .......u-moo .~
.....<1:>......... UYOll-'" HI.lI'O ,.~..:mn. Him"",, $1.10.1. """lIGI "',1OWlI. .,
~
g'"
"",,"^""",,"'--o
I _,......111"'"
~n
r:---~'-'
c "'
","'''m'''s~ II
II _ II
'N,""",""",.",,:I II
"'.0 "'~a" II It
II ))
, ,
"
N. "''''' ~ 11'" '">1m"
{,",'fOt""'''"N'tA''''"'"'
"
",
"'-c
c "
11'i----u~'" H:lll'O
II _"<
,
"
~,
O'OL
on
M",
"-
(.,01,"1081
"",',"'"';'dO
"lli",,"".""",,"""'-'
On
"
,~, n
~t II
"'",~i
'"
,m
,
)
,
-
'"""''''''"
"'''''"0"''0''
w,
00
"
o
,"
('"Illnl)
"~~
"
(",",ntr.l"
,.:;ml""'M"'1S
",,,,"O"L,.rund
39
SCHEDULE "D" OF AGREEMENT
Note: It is understood and agreed that this Schedule forms part of the Municipality's
Agreement.
CHECKLIST OF WORKS TO BE CONSTRUCTED
L Road restoration. complete with asphalt paving and curh and gutter 0
2. Stonn Water Management Plan, storm sewer system, modifi.::ations and
privatedraincollllections. ..
3. Sani1arysewersbuildingconnectionstothelotline "
4. Waler distribution system building connections to the lot line 0
5. Grading and requirements ofa site grading plan "
6. Undergroundelectricalserv:ice "
7. Utility obligations telephone,cab!et.v. 0
8. Sidewalks ..
9. Topsoil and sod on boulevard from property line to curb 0
10 Lot house number signs. 0
Note: Works Required Denoted by 0"
40
SCHEDULE"E" OF AGREEMENT
Note: It is understood and agreedthatthis Schedule fonns part of the Municipality's
Agreement.
ITEMIZED ESTIMATE OF COSTS OF CONSTRUCTION
OF EACH PART OF THE WORKS
RoadWorks
Water Servicing
Sanitary Servicing
Drainage Works
Electrical
Subtotal
134,000
99,300
68,200
180.000
77.700
559,200
Engineering
Subtotal
GST (6% rounded)
28.000
587,200
35.300
$622,500
41
SCHEDULE "F" OF THE AGREEMENT
Note: It is understood and agreed that this Schedule follllS part of the Municipality's
Agreement.
LIST OF LOTS UNSUITABLE FOR BUILDING PVRPOSES _ CLAUSE 6.3
None
42
SCHEDULE "G" OF THE AGREEMENT
NOTE: It is understood and agreed that this Schedule furrru; part of the Municipality's
Agreement.
OWNER'S FINAL GRADING CERTIFICATE
The undersigned hereby certifies to the Corporation of the Municipality of Kincardine (the
"Municipallty~)thatthefoundationsofthebuildingsandstructuresandanyopeningsinanysuch
foundation walls constructed on the following property:
STREET NO.
STREET
MUNICIPALITY
LOTffiLOCK
REGISTERED PLAN NO.
Have heenconstructed,atorabovelheelevationsillustrated on the overall Certified Building
Lot Site Plan (as approved by oron behalf of the Municipality) referred to in the Agreement
registered against the title to the above property as shown on lhe as-built grading survey
attached.
The undersigned further certifies to lhe Municipality that:
1. The final grading of the above referred to property has been completed in substantial
comphance WIth the Certified Building Lot Site Plan referred to in the Agreement
2. The grade elevation ofalllo! boundaries and comers including the front lot corners of the
property are in substantial compliance with the Certified BuiWing Lot Site Plan; and
3. The above lot has been graded to provide positive drainage in the front, rear and sideyard and
that there IS no area ofthepropertywhich is subject to ponding of water. and
4. That in all cases, the final grading confonns to the intent of the grading plant.
This certificate is given and delivered to the Municipality in full knowledge that the Municipality
relies on this certification in providing arelease of the applicable Agreement affecting this
property.
DATED at
Ontario this
day of
,200
Signature ofOLSlProfessional Engineer
NOTE: Copies of this Owner's .Final Grtuling Certificate are al'UiJable at the Municipality's
Building Department.
43
SCHEDULE "8" OF AGREEMENT
NOTE: It is understood and agreed that this Schedule forms part of the Municipality's
A_.
LANDS FOR MUNICIPAL PURPOSES TO BE CONVEYED TO THE MUNICIPALITY
Block 98 (or such blockas maybe renumbered between Lots 24 and 25.
LIST OF EASEMENTS TO BE GRANTED TO THE MUNICIPALITY
Easements for rear yard catch basins between Lots 5 &6, 10& 11, and 14& 15.
44
SCHEDULE"P' OF AGREEMENT
NOTE: It is understood and agreed that this Schedule forms part of the Municipality's
Agreement.
NO OCCUPANCY AGREEMENT
NOW THEREFORE TillS AGREEMENT WITNESSETH that ill consideration of other
good and valuable consideration and the sum of One ($1.00) Dollaroflawful money of Canada,
Ihe Pames hereto mutually covenant and agree as follows:
L In consideration of the Corporation of the Municipality of Kincardine issuing a building
permit to the Owner for
,the Owner
covenants and agrees that it will not apply for an occupancypennituntil the above
referred to services have been installed to the satisfaction of the Municipality;
2. The Municipality hereby acknowledges that it has a cash deposit from the Developerin
the sum of and will use its besl efforts to see to it that the
above referred to services are completed by
THIS AGREEMENT shall be binding upon and enure to the benefit oftbe parties hereto
and their respective heirs. executors. administrators, successors and assigns.
IN WITNESS WHEREUF the parties hereto have executed this Agreement.
SIGNED, SEALED AND DELNERED
This day of .200
,
,
(
( DEVELOPER (NAME OF DEVELOPER)
(
( TIfE CORPORATION OF THE
( MUNICIPALITY OF KINCARDINE
(
(
(Mayor
(
(
( CAO
(WehaveauthoritylobindtheCorporation.
45
SCHEDULE "J" OF AGREEMENT
Note:
It is understood and agreed thatthis Schedule forms part of the Municipality's Agreement.
APPLICATION FORREDUcnON OF SECURITY
To:
(Name of Municipality's Engineer), Engineer, Municipality of Kincardine
Developer:
(Name of Developer)
Agreement:
(Date of Agreement)
Property:
(Legal Description of Property)
AppIicauonNo.
{SpecifY number of application)
The undersigned, (Name of Developer's Engineer) being the Developer's Engineer, hereby
con:firms that the Wooo constructed as atlhe date of this Application have been instalJedbythe
Developer under the full time supervisian of the Developer's Engineer and in sccordance with
the requirements of the Agreement between the Developer and the Municipality.
The Works installed to the date llilreofand the calculation of the cost thereofare detaiJed in the
schedule attached hereto.
Further, the undersigned Developer's Engineer hereby confirms that the Works remaining to be
constructed as at the date of this Application and the cakulation of the estimated costtbereofare
also detailed in the scheduIe attached hereto.
This Application is given and delivered to the Municipality's Engineer with full knowledgethat
the Municipality's Engineer and the Municipalitywill relyupon the information contained herein
in granting a reduction of the security held by tbeMunicipality pursuant to Section 9.2 of the
said Agreement affecting the above property.
DATED at
Ontario this
day of
,200
SigilatureofDevelopcr'sEngineer
Name of Developer's Engineer
46
SCHEDULE "K" OF AGREEMENT
N01E: It IS understood and agreed that this Schedule forms part oflbe Municipality's
-"""".
FORM OF PARTIAL RELEASE:
PARTIAL RELEASE
IN FAVOUR OF:
Herein called the "Owner"
WHEREAS the Owner entered into certain obligations in favour of the Corporation oflbe
Municipality of Kincardine under an Agreement registered against the lands hereinafter
descnoed as Instrument No.
AND WHEREAS the Owner has satisfied and fulfilled all of those obligations.
NOW TIfEREFORE the Corporation of the Municipality of Kincardine releases the Owner from
the obligations oontained in the said Agreement. with the exception of the lot grading provisions
in Secllon6.5 in saidInstrumentNo._, as amende<!. and certiftes that ali other provisions of
that Agreement as amended, are no longer binding with respect to the said lands. The lands
released hereby are:
ALL AND SINGULAR that certain parcel ortract ofland and premist:S situate, lying and being
in the Municipality of Kincardine ( ), County ofBmce and being composed of Lot
RegIStered Plan -' the Municipality of Kincardine has, by Bylaw
registered in the said registry office as Instrument No. provided thaI this Partial
Release shall be executed by the CAO and sealed with its seal.
DATED this
clay of
.20_
47
SCHEDULE "L" OF AGREEMENT
NOTE: It i<l understood and agreed that this Schedule forms part of the Municipality's
Agreement.
CONDmONS OF DRAFT APPROVAL
The Conditions of Draft Approval for File No.
Bruce as attached hereto.
for the Corporation of the County of
CotlOmONSOFDRAFTPlANOFSllBOIVISlONAPPROVA!.
15112e79Ontariolnc.,cloKeldeoOavelopments
41T_2007-l12.22
MooIoIpanYo/"""""niine
PartofLclsA,B,andC,OonA,MuniclpaJityotKiocardme(fOl'mer
TownolKirlca,.jine}
Ju""n,2007
Owno"
F11.~
M"nldpol~:
SubjeGtLandS,
Dat&<>IPraftApp_
ThaApprnvaIAulhoolyoflheCorp,,",llonofll1.CounIyof_h.rebyiss"esDra~Apprcyallo
s..bdMsi>r> RIe 1<0. 41T_2007-<l2.22, w/1"" porlainstc PartofLoIs A, B,and C, Con A, Municlpalily
ofKi1cardna(fcm1erTown01 Kim:ar<linej.
The following comfdions have been sstablished by lhe Counly ofBruc9 and musll>e
metpriorto1hegranlingafrlllalapproval:
Mo. CondRlon
ldentiflcalion
1. That this aPl'""",1 app~"" to Plan of Subdivision FilE> 41T-2007.02.22 for 1582679
Ontarlo Inc., cloK"ld.,., DevolopmenlSPartolLolsA,B. and C, Con A Munlclpal/lyof
Kiocartf... (former Town 01 Kincardine) prepared by R.F. Dote Surveying Umlled
(P"".ctNo.3C400Revisiol1#3)_2007.01.10,
Publil>RoadsarldWalk""'\i1l
2. Th!Itltl.. roa<Iallowar>ceG shown on Illi. Plan ofS!Jbdivislon sIlaU be <ledloated on the
finelpJana.apubllehlghwaytolheapproprrateroadatllhority.
3. lhalthealreet(s)sh""benamedtolheselisfscllonolIheMunicipallyofKincaltl,,,...
4. That any dead ands..,dkJrcp"nsldesofroadallcwances """"""by this Plancf
Subdi\llslonshalbetetminatedmO.3ma1fe,.."..,rvestct>&con""Y<'<llcandheld,in
trust,bylheMuniclpelllycfKirlcard;ne"ntilreqlJkedfcrlllluraroadallowenoesorlhe
_opmenlofadjaoen!land. '
ParklandlOoenSDaCe
5. ThallheCl\lflSl"CCIIlVeYS land In lh"amounlcf5% oflhe land mduded in Ih<> Plan tOlhe
Municipality 01 Kirlcardlne for-pan;. purposes pUfSUSlJlto \he JI'"OIIisIt>ns cfSactioo
51(5)(s) oIm" Planrling Act R.S.O. 1990 o.P.13. AllemS!/ve/y, the Iwtlnicipallty of
KincardIne m"Ysooep!c:ssh-ln-l\eu cflhe.sidC<ifl\OSlylln""snd under provisions cf
Secljon51(S)ofIhePlannlngAot.R.S.O.1900o.P.13lheMunlcipalltyofKinoardj""ls
hefabyaulh_todoso.
Sul>dNieionAareement
6. Thstlheowoar"""'rmloanagraement>OilhlheMunicipa,lyolKirloardinetosallsfyall
lherequiremllllls,fi""ncialaodolherwisa,oflhemumC4palllyoonoeminglheprol'lskmof
roada, iostaJlalion ofee"'",,", facll~les and dramage
00
.
u
-.
'.
n
"
.-
~,
-,
.~ .
pi
, 'i
,.-
......~
>..
'"
W
~f'
oJ
,..
!' '.
"
"B
i"
, .""~
:Ull
".
'B,
ilf
,
'0
..
:u
,=
'.I
E,
St
!.
~~
-,
,.
. .
n ~
,~ ~
~u a
~~o !3!l
ilCl~ $"5,
,.. 0,
8:.l'I8 608:
"''lllj ill..
'!'i~ lIil!
~u ~ ~i
"'''''' 1-'" ~
.. wa. 0
. .-
.
.
.
.
~
.
.
,
~
.,
.
,
i
i i
i ~
I I
3:;': Ii
. .
t! ~
~~ ~
~.! i
I ~
.Pt
I. !.
un
s~ Sj
II I.
!I '.
"c. 1:~
,Ll.'!l ~l!!
]:.~ 1t8.
H ,!
"
.
~
,
s~
l.
,-
1~
.-
"
.
>.
n
,.
'.
, ,
i~
Ii
.~
i!
"
b~
g!
1:1
d
..
"c .
~ ~
Jli!~ J l I~ i
!ii~i ~'" ~ it Ii
i!~l.i if l~; ,g
"'1' ~i . IE l.i
I, n~ i~.' ~i ~!i lt~
.-. -. l.. .<i
. In"" .6<< I.
ii~jtj jl jii:!~
~iilii;1 ~iilJii
'~"" ,< "', ,.
0'..] 8. .,',''1
!~~~~t !~~ i~i~11i
~ E~gb~~ ~g~ ~~S~!2~~
· l~t~il lli f!ljfi:!
.' -1.- ."" I lOt-
eii~ 8.~ JEi<ll ~i1 11 81
Sfhd ~~~ Jl~ ~il~ g
I'~"l'" .,ls._ $ ,
'-1", '.. '] 0
!t~s~ 5 ~u ~.s~ z ~
,
, ,
o _
!J) :'l'
.
-
.
-
i!.9"
H~
n~
'"3.2,
· "
.j,-
, "
'I~j
!I"
"'!1i;'.2
.._,
~~.~
~ ~._ ii'I
8,"
..8
~3!1i
ni
!!~j,
,8,~
iLlil""t>
"'-1
."
,".
c1'!1!!!
i'!l'l. "
~'j~ *
='8" 'li
.~ ;
11-'" "
'iiHil
....
.c=> ''"
t--:>iE,Q
@
"g!~ .
i"i..ili
~".,
li~'
'~'i
z"~.<l
.g;~
"",'ffi!3
!tj<
"'z j
, .
d!!
~8h
i"i_!~
l~d
~oo
-~;.
, ..
ll: Clr~
'i.'
h;1
. .~
0-
Sl~1!
"h
.. ,
UH
.
l~&1
!;i
I!~
SI..,;
"I
I':.
'.
"
Iii
'.'
9 j~-
,~l
'.'
. 0
",
..l"[
;1,
~~.~
,IH
Ii!
~"iii
.."""
-s l!"~~
.!Ii~ !i
'" ~a:"
"
~'
"
-l
L
'~
~.
'.
l~
..
!~
!I
,.
c '
:.
I'
I!
.,
,-
Ii
IL
,w,
l"~'
"
i::1
I:"
-><
,
.
~
j
-,
III
'Ii~.
~ ~o~
:l: g'll~
> .,
.
.
,
I
!
,
. j
.
:ij~ liffi
!J," ~'"
iia.: ,,~
.,Il::IZ
, ~
>
'. "
~.!i z
,
H 0
~~ ;
, I
'Il.,!!/:
"'it 0:: "
> "'
I H I;
I it ;~
! I~ -15 s
"" ...s I
· '1 ~i ~
ihH:l
o ,,'" "5 'Is !
; !i !~! ~
fj !~ ii :€ ,Ii
! h .~, I i
" H hi' "I'
'" ", ~ ~
t II ,il ' ~
R F~ ,flli ~ g
h .', ~" :! i
'f ~.5,;; 'll:h K "
o!.. .,u ~~~ ! ~
I '111 0I':ii.!'! .s l!'
.~ ~ . i'~' , ·
g'O ~1!.5 "0 ,8 g
~s !.!!~ .5 ~ i f
~~ ~~il <ild ~ @
.
I~CI 2 ~ ~I ~III
I" , · Ii ,'"
:;; &": Ii i , 0"
. " ,. .
-' ..~jj Ii ~= I!! =
l'l.lrl t. 1 ~~ ~l~a.ll
"0' , . " I"
U'j I ~ H !'~i
u~~i! H ii ~Jr~
.'1~'ai~ I ii ~j ~~~!
iiUi.~ j~ ~i ~"Sj~ ~ ~
U!'lf'~ h ~~ lhI I i
~j ~ai\: ~ d H !!~.h e ~
, ,.~ l: ..., "1'1 ·
S'~'l!~'ll ~,; /'ill ~~ 3 ~ ~
l'l:ij~1 ~~ ~~ ~~ n!~~ !5 ~
~ ~l! ,I'" 1;" <e!l.. ~-.8
l~jh j~ 1!-1 ~II!f n!~l f Ii.
...2 ~ ~.'. ! -'" ",'l5 i
"';;!l.1i ,,~1: I ~ -&1 ~ ,,-. - ~..
na~~ 5i ~J ' :~ 'h;i i ~t
"Js ."J'll: ~5 -~ ",i'l5 o-!l~,~,~
I'ili' n n l'l 11m f __
lm~~ ~~ ~ !:ll ,ha-~ J/ >:.!!!.
~!~II l~ ~I ~sl It~l! ~ S~
.
.; ,..:
.
50
SCHEDULE "M" OF AGREEMENT
NOTE: It is understood and agreed thai this Schedule fonus part of the Municipality's
Agreement.
SPECIAL PROVISIONS
1. Phased Registtation
This Agreement is for Lots 1-~7 and associated blocks, Draft Plan 41T-207.02.22. A
subsequent Agreement will be required for the baLmce of the lots.
2. Parkland ThldicatiOD
The D..veloper and the Municipality agree that the parkland dedication will be satisfied
within the Agreement andupon regisb:lltion of the balance of the subdivision.
3. SaugeenValleyConservationAuthority
a) The Developer agrees to complete anyworks required by its "Stonnwater Management
Report" "Lot Grading Plan" ~"Erosion Sedimentation Control Plan" in accordance
with approved plans by the Saugeen Valley Conservation Authority.
b) The Deve\oper agrees to notify the Saugeen Valley Conservation Authority at least 48
hours pnor to the initiation of any on-site developmenl.
4. SeJ:'Vicing Prior to Registration
a) Notwithstanding Clause 2.3 (81 oflhe Agreement, the Developermay, subject to written
authorization from the Municipality, at his own risk, start constructwn prior to
registration of the plan provided the Municipalityhas been satisfied that:
i) Securities for the work have been received.
iil Liability insurance has been received.
iii) Municipal, Ministty of Environment and Saugeen Valley Conservation Authority
approvals of the design drawings have been received.
iv) The draft of the registered plan has been approved by the Municipality.
b) If the Developer receives authority to proceed under Section4 (a) above, it acknowledges
and agrees that such servicing work is done at its sole risk and the Developer agrees to
inderonify and save harmless theMunicipality with respect to any claim.. delllllnd.. action.
cost, suit or loss by anyone whomsoever which may occur as a result of the registration of
a plan of subdivision.
5. Road Construction and RestoratioD
The Developerwill be reconstructing a portion ofPenetangore Row to lower the grade
for drainage purposes. All costs associated with modifications to the storm sewer, road
reconstruction and paving, cnrb replacement. sidewalk replacement, ifwauanted, and
restoration of boulevards and driveways, will be borne by the Developer.
As the Developer will be cutting into the asphalt in other areas on Penetangore Rowand
Saratogato install municipal servi.ces..the Municipality and the Developerhave agreed
that the Developer will remove all of the asphalt and provide a base course of asphalt to
municipal standards aIong the full lengthofdisturbance of those two roads. The
Municipality has agreed that they will, as part of their armual paving program, provide the
surface course of asphalt on these roads so as to aVOid the disruption of the many patches
tbat would be required.
51
6. Senicing Drawings
The following is a list of servicing drawings that have been reviewed or are currently
under review by the Municipality. forthis development.
Dl:'aw:ingNo. Rev. Description Revision Date
N,.
SPI I Site Plan S 1.102007
CI I 2 LID' S 1.10,2007
C2 I P~'" R~ S .10,2007
C3 I Penetan oreRow S, .102007
C4 I Sarato aRnad S 1.10.2007
C5 I Saralo aRoad S 1.10.2007
C6 I LotGradin PIID 1.10,2007
C7 I Miscellaneous Details and Sept. 10,2007
lCalCroSS-Se.::tions
C8 I PhaseIlServic' - ) Se1.10,2007
C9 I Miscellaneous Details 3e 1.10 2007
CIO I PhasellServic' Prelimin S 1.10.2007
EI 0 ElectricalServici La out Notcomlete
Receipted as BR10817 on 200801 30
at 10:28
~ 3 Notice Of Subdivision Agreement
yyyy mm dd Page 1 of 60
The applicant!s) hereby applies to the Land Registrar.
I Properties
PIN
Description
Address
PIN
Description
Address
PIN
Description
Address
PIN
Description
Address
PIN
Description
Address
PIN
Description
Address
PIN
Description
Address
PiN
Description
Address
PIN
Description
Address
PIN
Description
Address
PIN
Description
Address
PIN
Description
Address
PIN
Description
Address
PIN
Description
Address
33318 - 0070 L T
LOT 1, PLAN 3M204, KINCARDINE.
KINCARDINE
33318 - 0071 LT
LOT 2, PLAN 3M204, KINCARDINE
KINCARDINE
33318 - 0072 LT
LOT 3, PLAN 3M204, KINCARDINE.
KINCARDINE
33318-0073 LT
LOT 4, PLAN 3M204, KINCARDINE.
KINCARDINE
33318-0074 LT
LOT 5, PLAN 3M204, KINCARDINE.
KINCARDINE
33318 - 0075 LT
LOT 6, PLAN 3M204, KINCARDINE.
KINCARDINE
33318 - 0076 LT
LOT 7, PLAN 3M204, KINCARDINE.
KINCARDINE
33318-0077 LT
LOT 8, PLAN 3M204, KINCARDINE.
KINCARDINE
33318 - 0078 LT
LOT 9, PLAN 3M204, KINCARDINE.
KINCARDINE
33318 - 0079 L T
LOT 10, PLAN 3M204, KINCARDINE.
KINCARDINE
33318 - 0080 LT
LOT 11, PLAN 3M204, KINCARDINE.
KINCARDINE
33318 - 0081 LT
LOT 12, PLAN 3M204, KINCARDINE.
KINCARDINE
33318 - 0082 LT
LOT 13, PLAN 3M204, KINCARDINE.
KINCARDINE
33318 - 0083 LT
LOT 14, PLAN 3M204, KINCARDINE.
KINCARDINE
.-.,
LRO # 3 Notice Of Subdivi$ion Agreement
Receipted as BR10817 on 2008 0': 30
at 10:28
The appllcant!s) hereby applies to the Land Registrar.
I Properties
PIN
Description
Address
PIN
Description
Address
PiN
Descriplion
Address
PiN
Description
Address
PIN
Description
Address
PIN
Descriptk,m
Address
PIN
Description
Address
PiN
Description
Address
PIN
Description
Address
PIN
Description
Address
PIN
Description
Address
PIN
Description
Address
PiN
Description
Address
PIN
Description
Address
yyyy mm dd Page 2 of 60
33318 - 0084 LT
'DT 15, PLA.N 3M204, KINCARDINE.
KIi~CARDINE
33318- 0085 L T
LOT 16, PLAN 3M204, KINCARDINE.
KINCARDINE
33318 - 0086 LT
lDT 17, PLAN 3M204, KINCARDINE
KINCARDINE
33318 - 0087 LT
LOT 18, PLAN 3M204, V;lNCARDINE.
KINCARDINE
33318 - 0088 LT
LOT 19, PLAN 3M204, KINCARDINE_
KINCARDINE
33318 - 0089 LT
LOT 20, PLAN ClM204, KINCARDINE_
KINCARDINE
33318 - 0090 LT
LOT 21, PLAN 3M204, KINCARDINE_
KINCARDINE
33318 - 009-1 LT
LOT 22, PLAN 3M204, KINCA!'lDINE.
KINCARDINE
3~J318 - 0092 L T
LOT 23, PLAN 3M204, KINCA,RDINE
KINCARDINE
33318 - 0093 L T
LOT 24, PLAN 3M204, KII~CARDINE.
KINCARDINE
33318 - 0094 LT
LOT 25, F'LAN 8M204, KINCARDINE.
KINCARDI~JE
33318 - 0095 L T
LOT 26, PLAN 3M204, KINCARDiNE.
KINCARDiNE
33318 - 0096 LT
LOT 27, PLAN 3M204, KINCARDINE.
K!~ICARDI~JE
33318-0097 LT
LOT 28, PLAN 3M204, KiNCARDINE.
KINCARDINE
.'
LRO # 3 Notice Of Subdivision Agreement
Receipted as BR1 0817 on 200801 30
at 10:28
The applicant!s) hereby applies to the Land Registrar.
I Properties
PIN
Description
Address
PIN
Description
Address
PIN
Description
Address
PIN
Description
Address
PIN
Description
Address
PIN
Description
Address
PIN
Description
Address
PIN
Description
Address
PIN
Description
Address
yyyy mm dd Page 3 of 60
33318 - 0098 L T
LOT 29, PLAN 3M204, KINCARDINE.
KINCARDINE
33318-0099 LT
LOT 30, PLAN 3M204, KINCARDINE.
KINCARDINE
33318 - 0100 LT
LOT 31, PLAN 3M204, KINCARDINE.
KINCARDINE
33318 - 0101 LT
LOT 32, PLAN 3M204, KINCARDINE.
KINCARDINE
33318 - 0102 LT
LOT 33, PLAN 3M204, KINCARDINE.
KINCARDINE
33318 - 0103 LT
LOT 34, PLAN 3M204, KINCARDINE.
KINCARDINE
33318-0104 LT
LOT 35, PLAN 3M204, KINCARDINE.
KINCARDINE
33318 - 0105 LT
LOT 36, PLAN 3M204, KINCARDINE.
KINCARDINE
33318 - 0106 LT
LOT 37, PLAN 3M204, KINCARDINE.
KINCARDINE
I Applicant(s)
The notice is based on or affects a valid and existing estate, right, interest or equity in land.
Name THE CORPORATION OF THE MUNICIPALITY OF KINCARDINE
Address for Service 1475 Concession 5, R. R. #5
Kincardine, ON N2Z 2X6
This document is not authorized under Power of Attorney hy this party.
This document is being authorized by a municipal corporation by Larry Kraemer, Mayor and John de Rosemo!!, Chief Adminstralive
Officer.
I Party To(s)
Share
Capacity
1582679 ONTARIO INC.
Name
Address for Service
c/o Dale Walden
P. O. Box 351
Kincardine, ON N2Z 2Y8
LRO # 3 Notice Of Subdivision Agreement
Receipted as BR10817 on 200801 30
at 10:28
The applicant(s) hereby appiies to the l.and Registrar.
[ Statements
yyyy mm dd Page 4 of 60
J
This notice is tor an indeterminate period
Schedule: See Schedules
I Signed By
John Michael Keip
216 Durham Street, Box 880
Walkerton
NOG 2VO
acting for
Applicant(s)
Signed 200801 30
Tel 519-881..3230
Fa~ 5198813595
JOhn Michaei Keip
215 Durham Street, Box 880
Walkerton
NOG 2VO
acting for Party
TO(8)
Signed 200801 30
Tet 519-881-3230
Fax 5198813595
I Submitted By
WAECHTER, MAGWOOD
215 Durham Street, Box 880
Walkerton
NOG 2VO
200801 30
Tel 519-881-3230
Fax 5198813595
l!eeSITaXeSIP;yment
Statutory Registration Fee
$60.00
Totai Paid
$60.00
~e Number
=:=J
Applicant Client File Number:
12874
r
I
I
I
I
~
.#
F:\wp\06138\07Sept19-Lakefield Urban Residential Agreement.doc
CORPORATION OF THE MUNICIPALITY OF KINCARDINE
SUBDIVISION AGREEMENT
FOR LAKE FIELD ESTATES SUBDIVISION
between
1582679 Ontario Inc.
- and-
THE CORPORATION OF THE MUNICIPALITY OF KINCARDINE
The Corporation oftbe Municipality of Kincardine
1475 Concession 5, R. R. 5
Kincardine, Ontario
N2Z 2X6
(0
THE CORPORATION OF THE MUNICIPALITY OF KINCARDINE
INDEX
Section 1 - Interpretation..............................................................................................................2
1.1 Definitions............................... .......................... ............................................ ...............2
1.2 List of Schedules.................. ....... .................................................................................3
Section 2 -- Order of Procedure......................,.............................................................................3
Section 3 -- Installation of Services...................,...........................................................................5
3.1 General........ ................. ................................................ ............ ................... .................5
3.2 Municipality's Legal and Engirteering Costs...............................................................5
3.3 Developer's Engirteer..... ........ ............................. .........................................................5
3.4 Works to be Installed...................................................................................................6
3.5 Approval of Plans ........................................................................................................6
3.6 Notification of Cornmencement...................................................................................6
3.7 Progress ofW orks........................................................................................................6
3.8 Scheduling ofW orks.................................................................................................... 7
3.9 Contractor ........... ..... .............. ........................... .......... ........... ................... ................... 7
3.10 Utility Costs and Charges ............................................................................................7
3.11 Access Roads ...............................................................................................................7
3.12 Movement ofFill ......................................................................................................... 7
3.13 Damage to Existing Plant.............................................................................................8
3.14 Signs......... ............. .............. ....... .... ............. ........... ......................................................8
3 .15 Testing........... ...................... ......:. ................ ............. ................................ ................ ....8
3.16 Erosion and Silting Control..........:..............................................................................8
3.17 Emergency Access .......................................................................................................8
3.18 Construction Refuse and Weeds ......:...........................................................................8
3.19 Dust Control.................................................................................................................9
3.20 Street Names ................................................................................................................9
3.21 Municipal Street Numbers ............:..............................................................................9
3.22 Blasting......... ......................................... ....... ..... ............................ .......................... ....9
3.23 Driveways ....................................................................................................................9
3.24 Contaminants .............................................................................................................1 0
Section 4 -- Acceptance of Works............................................................................................... 10
4.1 Stages of Construction and Services..........................................................................10
4.2 Inspection and Acceptance of the Works................................................................... 10
4.3 Final Acceptance of the Works..................................................................................l0
4.4 Acceptance During Winter Months ...........................................................................11
4.5 Use of Works by Municipality...................................................................................ll
4.6 Replacement of Survey Bars......................................................................................11
4.7 Ownership of Services ...............................................................................................11
Section 5 - Maintenance of W orks ............................................................................................11
5.1 Maintenance ofW orks ...............................................................................................11
5.2 Road Maintenance .....................................................................................................12
5.3 Emergency Repairs ....................................................................................................12
Section 6 - Drainage and Landscape Design:...........................................................................12
6.1 Drainage ....................... ....................... ................ ................................ ................ ...... ..12
6.2 Preservation of Trees ................. ..... ,'.:............................. ........................................... .12
6.3 Lots Unsuitable for Building .....................................................................................13
6.4 Lot Grading ..................... ............ ................................... ................... ....................... ..13
6.5 Maintenance of Lot Grading ......................................................................................15
..
7
Index (cont'd)
Section 7 -- Lands to be Conveyed..............................................................................................15
7.1 Lands for Municipal Purposes ...................................................................................15
7.2 Easements . ................... ........ .............. ....................................................................... .15
7.3 Turning Circles. ............ ...... .............................. ..................... ........... ................. ....... .15
Section 8 - Administration .........................................................................................................16
8.1 Voiding Agreement....................................................................................................16
8.2 Developer's Expense .................................................................................................16
8.3 Phasing.......... ........................................................ ............................. ...................... ..16
8.4 Developer's Liabilities ........... ........... .......... ........................................................... ....16
8.5 Insurance..... ...................................................... ......... .............................................. ..17
8.6 Legal Notice to Developer .........................................................................................17
8.7 Registration............ ............. ...................... ............ ......... ................... ..... ............... .....17
8.8 Mortgages/Encumbrances..........................................................................................17
8.9 Requirements for Building Permits ...........................................................................17
8.10 Requirements for Occupancy.....................................................................................18
8.11 Special Building Permits/Model Homes.................................................................... 19
8.12 Right to Enter into an Agreement ..............................................................................19
8.13 Successors and Assigns..............................................................................................19
8.14 Notification to Purchaser ...........................................................................................19
8.15 Scheduling, Progress and Completion.......................................................................20
8.16 No Municipal Liability ..............................................................................................20
8.17 Assignment ................................................................................................................20
8.18 Conflict.... .......................... ...................... ........ ..........................................................20
8.19 Severability ................... ......... .............. ................. ................. .................................. ..20
8.20 Amendment................................................................................................................20
8.21 Further Assurances.... ...................... .................... .................................. .................... .21
8 .22 Joint and Several........ ......... ..................... ................................................................. .21
Section 9 -- Financial Provisions.................................................................................................21
9.1 Development Charges, Drainage and Local Improvement Charges..........................21
9.2 Securities....... ..... ............. ................... .................................................. ......................21
9.3 Reduction of Securities .......... .... ............................ ........... ...........................................22
9.4 Statutory Declaration of Accounts Paid.....................................................................22
9.5 Construction Lien Act.................................... ........ ....... ......................... ............. .......23
9.6 Partial Release......... ........... .............. ................ ................ ............. ...... ................... ....23
Section 10 -- Special Provisions
- See Schedule "M" ..................................................................................................23
Section 11 -- Signatures ...............................................................................................................24
.
Index (cont'd)
Schedule "A"
Schedule "B"
Schedule "C"
Schedule "D"
Schedule "E"
Schedule "F"
Schedule "G"
Schedule "H"
Schedule "I"
Schedule "J"
Schedule "K"
Schedule "L"
#
LIST OF SCHEDULES
Description of Lands Being Subdivided..........................................................25
Plan of Subdivision ..........................................................................................26
Municipal Servicing Standards ........................................................................27
Checklist of Works to be Constructed .............................................................39
Itemized Estimate of Costs of Construction of Each Part of the Works..........40
List of Lots Unsuitable for Building Purposes ................................................41
Owner's Final Grading Certificate......... ........ ......................... ................... ......42
List of Lands for Municipal Purposes and Easements to be Granted
to the Municipality ..... ... .................. ............ .......... .... ............................ ...........43
No Occupancy Agreement...............................................................................44
Application for Reduction of Security .............................................................45
Form of Partial Release....................................................................................46
Conditions of Draft Approval..........................................................................47
Schedule "M" -- Special Provisions............................................................................................50
r
MUNICIPALITY OF KINCARDINE
LAKEFIELD ESTATES SUBDIVISION AGREEMENT
THIS AGREEMENT made in triplicate on the 19th day of September, 2007 A.D.
BETWEEN:
1582679 Ontario Inc.
hereinafter called the "Developer" of the FIRST PART
- and-
THE CORPORATION OF THE MUNICIPALITY OF KINCARDINE
hereinafter called the "Municipality" of the SECOND PART
WHEREAS the Developer is the owner of the Land described in Schedule "A" to this
Subdivision Agreement (hereinafter called the "Agreement") and proposes to subdivide it for the
purpose of selling, conveying, or leasing it in lots, by reference to a Registered Plan of
Subdivision.
AND WHEREAS the Developer declares that it is the registered owner of the lands and has
applied to the County of Bruce (hereinafter called the "County), for approval of a Plan of
Subdivision (hereinafter called the "Plan"), which is annexed hereto as Schedule "B" to this
Agreement.
AND WHEREAS the Municipality has been authorized by the County to require the Developer
to agree to construct and install certain municipal services as hereinafter provided and herein
referred to as the "Works" set out in Schedule ;'D" and to make financial arrangements with the
Municipality for the installation and construction of required services before final approval of the
Plan by the County.
AND WHEREAS the Developer is required to dedicate for public purposes certain portions of
the Lands or make a cash payment to the Municipality in lieu of dedicating such land.
AND WHEREAS the word "Developer" where used in this Agreement includes an individual,
an Association, a Partnership, or a Corporation and wherever the singular is used herein, it shall
be construed as including the plural.
NOW THEREFORE THIS AGREEMENT WITNESSETH that in consideration of other good
and valuable consideration and the sum of One Dollar ($1.00) oflawful money of Canada, now
paid by each ofthe parties hereto to each of the other parties hereto, (the receipt whereof is
hereby acknowledged), the parties hereto hereby covenant, promise and agree with each other as
follows:
/t:1
2
SECTION 1- INTERPRETATION
1.1 Definitions
The terms defined in this Section 1.1 shall have the following meanings unless the context
expressly or by necessary implication otherwise requires:
"Agreement" means this Agreement titled "Subdivision Agreement".
"Business Day" means any day that is not a Saturday, Sunday or statutory holiday in the
Province of Ontario.
"Certificate of Final Acceptance" means the certificate issued by the Municipality after
satisfaction of the conditions identified in Section 4.3.
"Certificate ofInspection Re: Readiness for Occupancy" means the certificate issued by the
Municipality after satisfaction of the conditions identified in Section 8.10.
"Certificate of Preliminary Acceptance" means the certificate issued by the Municipality after
satisfaction of the conditions identified in Section 4.2.
"Chief Administrative Officer (CAO)" means the Chief Administrative Officer or his/her
designate for the Municipality of Kincardine.
"Chief Building Official (CBO)" means the Chief Building Official or designate for the
Municipality of Kincardine.
"Conservation Authority" means the Saugeen Valley Conservation Authority and its
successors and assigns.
"County" means the County of Bruce and its successors and assigns.
"Damage/Lot Grading Deposit" means the amount of $2,500.00 per lot or block shall be paid
by the Developer or Owner to the Municipality by way of cash or letter of credit as described in
Section 8.9 of this Agreement.
"Developer" means, collectively, 1582679 Ontario Inc. and their respective successors and
assigns.
"Land" means the real property which is the subject of the Plan, the legal description of which is
attached as Schedule "A".
"Municipality" means the Corporation of the Municipality of Kincardine, and its successors and
assigns.
"Owner" means the Owner of a lot or block and may include the "Developer".
"Plan" means the plan of subdivision relating to the Land, a draft copy of which is attached as
Schedule "B".
"Public Works Manager" means the Public Works Manager or his designate for the
Municipality of Kincardine.
"Works" means the works and services described in Schedule "D".
II
3
1.2 List of Schedules
The following schedules are attached to and form part of this Agreement:
Schedule "A"
Schedule "B"
Schedule "c"
Schedule "D"
Schedule "E"
Schedule "F"
Schedule "G"
Schedule "ff'
Schedule "I"
Schedule "J"
Schedule "K"
Schedule "L"
Schedule "M"
Description of Lands Being Subdivided
Plan of Subdivision
Municipal Servicing Standards
Checklist of Works to be Constructed
Itemized Estimate of Costs of Construction of Each Part of the Works
List of Lots Unsuitable for Building Purposes
Owner's Final Grading Certificate
List of Lands for Municipal Purposes and Easements to be Granted
to the Municipality ,
No Occupancy Agreement
Application for Reduction of Security .
Form of Partial Release
Conditions of Draft Approval,
Special Provisions
SECTION 2 - ORDER OF PROCEDURE
2.1 Upon application to the Municipality for the preparation of an Agreement the Developer
shall:
(a) Pay to the Municipality the sum often thousand ($10,000.00) dollars as a deposit
in respect of the Municipality's legal and engineering costs referred to in Section
3.2 (a) herein.
(b) Submit a General Plan outlining the services to be installed.
( c) And may be required to sign a predevelopment agreement which includes:
. the intent of the developer;
. the intent of the Municipality;
. a statement outlining the areas of study that will be required prior to the
Municipality agreeing to proceed with the development (by means of a
development agreement);
. a statement outlining the deposit amount of $1 0,000 and the terms of its use;
. a general timeline for review of the development project.
2.2 Prior to Registering the Agreement the Developer shall:
(a) Deposit with the Municipality Securities and Insurance as outlined in the
Agreement.
(b) Pay in full any outstanding taxes or drainage, local improvement charges and
charges under the Municipal Act including outstanding sewer rates and/or water
rates.
/:.z
4
(c) Mutually agree with the Municipality on the parcel ofland to be deeded to the
Municipality for parkland or the amount of cash to be given to the Municipality
in lieu of Parkland.
(d) Pay the amount in lieu of parkland to the Municipality or deposit the
Transfers/Deeds of Land for the parkland with the Municipality.
(e) Provide proof of postponement of any encumbrances on the lands.
(f) Deposit with the Municipality's Solicitor, copies ofthis Agreement executed by
the Developer, to be executed by the Municipality and retained by the
Municipality's Solicitor forregistration as hereinafter provided.
(g) Deliver to the Municipality's Solicitor written authorization to register this
Agreement or Notice of this Agreement both before and after registration of the
Plan, and a cheque in respect of the cost of the said registrations where upon the
Municipality's Solicitor shall register this Agreement.
2.3 Prior to starting construction on tl,1e Services, the Developer shall:
(a) Have obtained final approval of the Plan from the County and have obtained
Registration of the Plan.
(b) Deposit executed deeds to the Municipality, free and clear of all encumbrances,
for any lands to be conveyed to the Municipality (and such deeds to be deposited
with the Municipality) prior tb the CAD's clearance letter to the County of
Bruce.
(c) Have submitted and obtained th~ written approval of the Municipality's Engineer
for the following all to be done in accordance with the Municipal Servicing
Standards of the Municipality:
. The Drainage Plan;
. The Lot Grading Plan;
. The Service Layout Plan for underground electrical services, telephone, gas,
etc.;
. Final approved drawings for all Works required in Schedule "D" to this
Agreement.
(c) Submit to the Municipality the Ministry of the Environment's Certificate of
Approval for the Water Supply and Distribution System, the Sewage Collection
System, and the Storm Sewer System and Storm Water Management Works.
(d) Provide written confirmation of having obtained the approval for drainage, road
crossings, encroachment, etc. of all road authorities including the Municipality,
County, Conservation Authority, the Ministry of Transportation of Ontario and
any other authority involved.
2.4 Prior to the sale of any lot and/or prior to the issuance of building permits the
Developer shall:
(a) Have complied with all reqllire):Uents of Section 8.9.
2.5 Prior to any person occupying any building, the Developer shall:
(a) Have complied with all the requirements of Section 8.10 of this Agreement.
/3
5
SECTION 3 -- INSTALLATION OF SERVICES
3.1 General
Upon approval of the Plan by the County, the Developer shall design, construct and
install at his own expense and in good workmanlike manner to the servicing standards
of the Municipality as set out in Schedule "C" to this Agreement.
3.2 Municipality's Legal and Engineering Costs
(a) The Developer agrees to pay the Municipality's cost of the Municipal Solicitor
and of the Municipality's Engineer's invoices for the checking of plans and
specifications and for supervision and inspection on behalf of the Municipality.
(b) The Developer shall be invoiced regularly by the Municipality for all costs
incurred by the Municipality with respect to this Agreement.
(c) The Developer shall reimburse the Municipality for all costs incurred by the
Municipality as referred to in Section 3.2 (a) herein, within thirty (30) days of
each billing, failing which the Municipality and its agents shall cease all work
with respect to the review of the Subdivision.
(d) The deposit referred to in Section 2.1 (a) of this Agreement shall be retained by
the Municipality as a float against any unpaid bills and such deposit (or the
balance thereof, if any) shall be returned to the Developer at Final Acceptance of
the Subdivision by the Municipality and the Municipality being satisfied, in its
discretion, that all costs in Section 3.2 (a) herein and any contingencies with
respect to the Subdivision have been paid in full.
(e) The Developer shall pay to the Municipality, on thirty (30) days written notice
from the Municipality, such amount as is necessary to maintain the deposit
referred to in Section 2.1 at the sum often thousand ($10,000.00) dollars, failing
which the Municipality and its agents shall cease all work with respect to the
review of the Subdivision.
3.3 Developer's Engineer
The Developer shall employ engineers registered with Professional Engineers Ontario
and approved by the Municipality:
( a) To prepare designs;
(b) To prepare and furnish all required drawings;
(c) To prepare the necessary contract(s);
(d) To obtain the necessary approvals in conjunction with the Municipality, the
County Health Unit and the Ministry of the Environment, and others as required.
(e) To provide the field layout, the contract documentation and the full time
supervision of construction. .
(f) To maintain all records of construction and upon completion, to advise the
Municipality's Engineer of all construction changes and to prepare final "as
constructed" drawings. Digital files of the "as constructed" drawings shall be
submitted to the Municipal Engineer and the Municipality prior to the issuance of
the Certificate of Final Acceptance. Digital files shall be in the format of
AutoCAD dxf or dwg files, coordinates ofUTM Nad 27 zone 17 North or UTM
Nad 83 zone North with and accuracy of 1 meter or less.
(g) To act as the representative ofthe De"eloper in all matters pertaining to the
construction.
/1
6
(h) To provide co-ordination and scheduling to comply with the timing provisions of
this Agreement and the requirements of the Municipality's Engineer, for all
works specified in this Agreement.
(i) To provide certification that the installation of services was in conformance to
said plans and specifications, such certification to be in a form acceptable to the
Municipality's Solicitor and the Municipality's Engineer.
G) To take such other actions as may be required by the Municipality, acting
reasonably, for the completion ofthe subdivision in accordance with this
Agreement and good engineering practices.
3.4 Works to be Installed
The Works to be installed are set out in Schedule "D" to this Agreement. This schedule
is to set out the works in general terms only and shall not be construed as covering all
items in detail. If at any time and from time to time during the development, the
Municipality's Engineer is of the opinion that additional works are necessary to provide
adequately any of the public services required by the Plan, the Developer shall, at his
expense, construct, install or perform such additional works at the request of the
Municipality's Engineer.
3.5 Approval of Plans
The detailed plans and specifications .of all services must be submitted by the
Developer to the Municipality's Engineer for endorsement of approval and such
endorsement of approval shall in no way absolve the Developer or its consulting
Engineers of responsibility for errors in or omissions from such plans and
specifications.
3.6 Notification of Commencement
The Developer shall not commence the construction of any of the works until the plan
has been registered and the Developer has provided 72 hours written notice to the
Municipality's Engineer of his intent to commence work. Should, for any reason, there
be a cessation or interruption of construction, the Developer shall provide 72 hours
written notification to the Municipality's Engineer before work is resumed.
3.7 Progress of Works
The Developer shall install all Works in a timely manner, in accordance with the
requirements of Schedule "c" and this Agreement. Ifhe fails to do so, having
commenced to install the aforesald works, fails or neglects to proceed with reasonable
speed, or in the event that the aforesaid works are not being installed in the manner
required by the Municipality, then upon the Municipality giving seven (7) days written
notice by prepaid registered mail to the Developer, the Municipality may, without
further notice, enter upon the said lands and proceed to supply all materials and to do
all the necessary works in connection with the installation of the said works, including
the repair or reconstruction of fault work and the replacement of materials not in
accordance with the specifications, and to charge the cost thereof together with an
engineering fee often percent (IO%)ofthe cost of such materials and works to the
Developer who shall forthwith pay thl( same upon demand. If the Developer fails to
pay the Municipality within thirty (3()) days of date on the bill, the money owing may
be deducted from the cash deposit, letters of credit, or other securities. It is understood
in the event that the Municipality must enter upon said lands and have works completed
or repaired due to situations as outlined above any or all original mylars and
specifications prepared by the Developer's Engineer must be turned over to the
Municipality's Engineer for his use should he require same. It is understood and agreed
between the parties hereto that such entry upon the lands shall be as agent for the
Developer and shall not be deemed for any purpose whatsoever, as an acceptance or
assumption of the said Works by the Municipality. The Municipality, in addition to all
other remedies may refuse to issue building permits until such Works are completely
installed in accordance with the requirements of the Municipality.
/~
7
Without limiting the obligations of the Developer herein, if the Developer shall default
on the performance of any term, covenant or provision of this Agreement and if such
default shall continue for ten (10) days after the Developer receives written notice of
such default by the Municipality (or such shorter time as may be required in the cases
of an emergency or other urgent matters or as otherwise provided for herein), the
Municipality may perform that obliga,tion on the Developer's behalf and may enter onto
the lands constituting the Plan for this purpose. If the Municipality is compelled or
elects to incur any expense in connection with its performance of the Developer's
obligations (including any engineering or legal fees incurred in connection with such
actions), any reasonable costs so incurred by the Municipality, together with all interest
thereon and any damages incurred, shall be payable by the Developer and shall be
collectible by the Municipality in like manner as municipal taxes. The Developer also
acknowledges and agrees that the Municipality has the right to draw down any Letters
of Credit, cash or other security for the purpose of collecting any such expenses
incurred by the Municipality.
3.8 Scheduling of Works
Prior to the start of construction and prior to the issuance of building permits, the
Developer shall supply for the approval of the Municipality's Engineer a Schedule of
Works setting out the order in which he considers the various sections of the works
within the Plan will be built. The Municipality's Engineer may amend this schedule
and the Developer must construct, install or perform the work as the Municipality's
Engineer from time to time may direct.
3.9 Contractor
The said services shall be installed by a contractor or contractors retained by the
Developer and approved in writing by the Municipality's Engineer.
3.10 Utility Costs and Charges
The Developer shall deal directly with all Utility companies. He or his Consulting
Engineer, shall obtain all approvals and permits and pay all fees and charges directly to
the appropriate Utility.
3.11 Access Roads
All access roads must be maintained by the Developer in good repair acceptable to the
Municipality's Engineer during the time of construction. This shall include the removal
of mud tracked from the Subdivision as well as dust control. No roadway outside the
limits of the proposed Subdivision may be closed without the written consent of the
Municipality. To obtain such consent, the Developer shall advise the Chief
Administrative Officer (CAD), not later than 14 days prior to the proposed closure, of
the date, time and duration they wish to close a roadway. All costs for advertising the
closure and signage shall be borne by the Developer. The Municipality reserves the
right to limit or prohibit the useof any existing access road by the Developer.
3.12 Movement of Fill
The Developer covenants and agrees that it shall not dump nor permit to be dumped
any fill or debris on, nor shall it remove or permit to be removed any fill, topsoil, trees
or shrubs from any public lands, other than roads, without the written consent of the
Municipality's Engineer. The Developer further agrees that no topsoil shall be
removed from the lots and/or blocks except for construction purposes within the
development and then such topsoil shall be stockpiled during grading operations and as
each building is completed, the topsoil so stockpiled shall be replaced on the ground
around each building to comply with the Municipal standards, and the replacing of such
topsoil shall include all surfaces not covered by buildings, driveways or pavement
within the development. Excess tops'oil may be removed from the site with the
approval of the Municipality's Public Works Manager.
/(P
8
3.13 Damage to Existing Plant
The Developer shall repair any damage caused to any existing road, road allowance or
existing structure or plant located on the road allowance as a result of the development
and shall pay for any costs involved in relocation of existing service such as hydrants,
telephone poles, hydro poles, pad mount transformers, cubicles and pedestals, etc.,
which may be necessary because of the development.
3.14 Signs
Signs at least 1.2 m x 1.8 m shall be erected by the Developer in an approved location
at each entrance to the Subdivision. .The signs shall read as follows:
"Roads Not Assumed by Municipality - Use at Your Own Risk".
These signs shall be installed prior to the start of construction and be removed after all
the roads have received a Certificate of Final Acceptance.
3.15 Testing
The Municipality's Engineer may have any qualitative or quantitative tests made of any
materials which have been or are proposed to be used in the construction of any of the
works required by this Agreement, or may require additional television camera or soil
tests to be carried out, and the cost of such tests shall be paid by the Developer within
ten days of the account being rendered by the Municipality. Nothing herein shall
relieve the Developer of its responsibility to carry out any tests required by good
engineering practice.
3.16 Erosion and Silting Control
The Developer must take all necessary precautions to prevent erosion and
sediroentation of sewers, ditches, culverts, slopes, etc., both within the Development
and downstream during construction and completion of servicing. Failing adequate
precautions being taken, the Developer will be responsible for correcting any damages
and paying all maintenance costs resulting therefrom.
3.17 Emergency Access
The Developer shall at all tiroes during construction and development of the Works
maintain emergency access to the land to the satisfaction of the Municipality's
Engineer.
3.18 Construction Refuse and Weeds
The Developer, and each subsequent Owner of Lots or Blocks within the Plan, shall
regularly dispose of all construction refuse, debris or weeds whether it be from site
servicing or house building or any other source related to the development of the site, in
an orderly and sanitary fashion. If the Developer or subsequent Owner of the Lots or
Blocks within the Plan fails to remove and dispose of construction refuse, debris or
weeds to the satisfaction of the Municipality's By-law Officer, the Municipalitymay
give written notice to the Developer or lot Owner. Ifthe Developer or each subsequent
Owner of Lots or Blocks within the Plan fails to dispose of the refuse, debris or weeds
within forty-eight (48) hours after receiving a written request from the Municipality to
do so, the Municipality may, without further notice, undertake such removal and
disposition and the cost thereof shall be paid by the Developer or each subsequent
Owner of the Lots or Blocks within the Plan forthwith upon demand, which costs shall
include all expenses incurred by the Municipality in carrying out such removal and
disposition. The burning of construction refuse, debris or weeds, whether it be from
site servicing or house building or any other source related to the development of the
site on any lands within the Plan is prohibited.
//
9
3.19 Dust Control
Until the Final Acceptance of all Services to be constructed under this Agreement, the
Developer shall use such reasonable method to prevent any dust problem to traffic or
home occupants as the Municipality shall deem necessary and for this purpose the
Public Works Manager shall notify the Developer in writing from time to time of the
requirements of the Municipality.
3.20 Street Names
The Developer shall name all streets within the Land forming part ofthe Plan with
names approved by the Municipality.. .
3.21 Municipal Street Numbers
(a) All Lot, Block or building numbers for use within the Plan shall be allocated by
the Chief Building Official (CBO). To obtain such allocation, the Developer
shall furnish the CBO with a copy of the Plan as registered upon which the CBO
will designate the proper numberS for each Lot, Block or building.
(b) The Developer shall display by m.eans of a legible sign at least l' xl' to be
erected on each Lot or Block within the Plan, the Lot or Block number as shown
on the Plan and the street number and Lot or Block number for each Lot or Block
prior to the issuance of a Building Pennit for that Lot or Block which sign shall
remain until such time as the building on such Lot or Block is occupied in
accordance with the provisions of this Agreement.
(c) Each Owner shall cause the street number so provided to be placed and
maintained in a conspicuous position in the front ofthe property upon occupancy.
3.22 Blasting
The Developer agrees that no blasting will be undertaken without the written consent of
the Municipal Engineer.
3.23 Driveways
The Developer hereby agrees that the driveways for all lots will be in a location and
have a width and design as may be approved by the Municipality. Without in any way
limiting the discretion of the Municipality, the location of the driveways may be further
limited by special revision in Schedule "M" of this Agreement. Further, all driveways
for all lots in the plan should be located in a manner that will minimize the amount of
snow that will accumulate in the lot's driveway. The location of driveways is
particularly important with respect to all comer lots located in the plan, as these
driveways entrances must be located as far as possible from the street comer to
minimize the amount of snow that will block these driveways during the Municipality's
efforts to remove snow.
Further, the Developer hereby agrees that he will be responsible for, or will provide for
agreements with subsequent owners, with respect to responsibility, to complete all
driveway entrances, for their full width, with a hard surface consisting of asphalt or
concrete pavement. This hard surface shall extend to the edge of the municipal road
allowance.
/fS.
10
3.24 Contaminants
In the event the Developer discovers any waste, contaminants, pollutants, hazardous
substances or any other similar substances that may be detrimental to the environment
during the development of the lands constituting the Plan, the Developer hereby agrees
to notifY the Municipality and the Ministry of the Environment immediately and take
all necessary steps and remedial efforts required by the Ministry of the Environment
and the Municipality to remove such waste, contaminants, pollutants, hazardous
substances or other substances that could be detrimental to the environment. In taking
such action, the Developer shall fulfill all legislative requirements for the remediation
and clean-up oflands constituting the Plan and shall comply with all legislative
requirements regulating the removal, transportation and disposal of such waste,
contaminants, pollutants, hazardous substances or any other similar substances from the
said lands.
SECTION 4 - ACCEPTANCE OF WORKS
4.1 Stages of Construction and Services
The Municipality will grant Preliminary or Final Acceptance of servicing based upon
three (3) stages of construction; and when the development is phased, within the whole
of each phase as approved by the Municipality. Stages of construction are as follows:
(a) Stage I - consists ofall underground Works including storm sewers and storm
water management facilities, sanitary sewers, watermains and the completion of
Granular "B" road base and a portion of the Granular "A" for a riding surface.
(b) Stage 2 - services shall include the balance of the road works including granular,
curbs and gutter, base asphalt, grading of boulevard areas, construction of all
drainage swales and outlets, sidewalks, installation of street and traffic sigus,
conduits, piping and facilities for the completion of electrical servicing, street
lighting and other utilities such as gas, telephone and Cable TV.
(c) Stage 3 - services including the final coat of asphalt, topsoil and sodding, trees,
fencing and any other requirements of this agreement.
4.2 Inspection and Acceptance of the Works
When all of the services in any stage of servicing as identified above have been
completed and the Municipality's Engineer has been given written certification by the
Developer's Engineer that such services have been constructed in each stage in
accordance with the approved plans and specifications in this Agreement and upon
satisfactory inspection by the Municipality's Engineer, the Municipality's Engineer will
recommend that the Municipality grant a Certificate of Preliminary Acceptance. This
Certificate may include a list of minor deficiencies which the Developer must repair.
The services shall then be subject to a guaranteed maintenance period as described in
Section 5.1.
4.3 Final Acceptance of the Works
On receipt of a written request from the Developer for final inspection and final
acceptance following completion of the guaranteed maintenance period outlined in
Section 5.1, the Municipality's Engineer will complete an inspection and if there are no
deficiencies, will recommend to the MUnicipality that the Certificate of Final
Acceptance be issued. This Certificate will be issued provided that the Developer has
paid all accounts to the Municipality and the Municipality is:
.
Satisfied the applicable services have been completely installed;
.
Satisfied all repairs or maintenance work on the applicable services have been
completed.
/9
11
and the Municipality has:
. Approved the formal certification of final completion from the Developer's
Engineer certifying that all Works and services have been installed;
. Received as-built drawings as detailed elsewhere in this Agreement.
4.4 Acceptance During Winter Months
The Municipality will not be required to provide Certificates of Preliminary or Final
Acceptance during the winter months or any other time of year when inspection of the
Works and services is impractical due to snow cover or other adverse conditions.
4.5 Use of Works by Municipality
The Developer agrees that:
(a) The Works may be used prior to acceptance by the Municipality, or other
authorized persons for the purposes for which such works were designed.
(b) Such use shall not be deemed an acceptance of the Works by the Municipality.
(c) Such use shall not in any way relieve the Developer of his obligations in
respect of the construction and maintenance ofthe Works so used.
4.6 Replacement of Survey Bars
Prior to the final acceptance by the Municipality, the Developer shall deliver to the
Chief Building Official (CBO) a statement from an Ontario Land Surveyor that after
the completion of the work, he has found, in satisfactory condition or replaced all
survey monuments and iron bars as shown on the registered plan.
4.7 Ownership of Services
Upon the issuance to the Developer of the Certificate of Final Acceptance, the
ownership of the services described shall vest in the Municipality and the Developer
shall have no claim or rights thereto except those occurring as an owner of the lands
abutting the streets where such services are installed.
SECTION 5 - MAINTENANCE OF WORKS
5.1 Maintenance of Works
The Developer will be responsible for the repair and maintenance of all services
including hydro costs for street lights, until a Certificate of Final Acceptance is issued
by the Municipality. This maintenance period shall extend for two (2) years from the
date of the Certificate of Preliminary Acceptance for each Stage of the Works. During
this maintenance period, a 10% security holdback shall be retained by the Municipality
in accordance with the provisions of Clause 9.3 (e) of this agreement. If during this
period, the Developer fails to carry out maintenance work within seventy-two (72)
hours after receipt ofthe request from the Municipality, then the Municipality's
Engineer or Public Works Manager may, without further notice, undertake such
maintenance work and the total costs of such work, including engineering fees, shall be
borne by the Developer. If the Developer fails to pay the Municipality within thirty
(30) days of the date of billing then the money owing may be deducted from the
deposited securities. Towards the end of the Maintenance Period, the Developer shall
make written request to the Municipality for a final inspection to be made in respect to
the issuance ofthe Certificate of Final Acceptance.
d<O
12
5.2 Road Maintenance
The Developer will be responsible for the maintenance of the roads until final
acceptance.
Summer maintenance shall include grading, dust control and general clean-up of the
site. Winter road maintenance shall include all plowing, sanding and salting to assure
proper vehicular access within the Subdivision.
In the event that proper maintenance or snow removal is not provided by the Developer,
the Municipality, through its servants, contractors or agents may provide maintenance
and/or remove snow without notice to the Developer. Such work will be carried out at
times deemed to be an emergency by the Public Works Manager. All costs of such
work shall be paid by the Developer within thirty (30) days of date of billing or
otherwise may be deducted from the deposited securities. The Developer further agrees
that any work done by the Municipality pursuant to this contract before the roads are
accepted by the Municipality shall not be deemed in any way, to be an acceptance by
the Municipality ofthe roads in the said Subdivision upon which such work is done.
The Developer acknowledges that the Municipality, in providing maintenance or during
snow removal, may damage or interfere with the works of the Developer and cause
damage to such works and the Developer hereby waives all claims against the
Municipality that he might have arising therefrom and covenants that he will make no
claim against the Municipality for such interference or damage. Representation may be
made requesting that the Municipality consider entering into a separate Agreement with
the Developer to undertake the winter toad.tuaintenance within the Subdivision.
5.3 Emergency Repairs
Employees or agents of the Municipality may enter onto the Land at any time or from
time to time for the purpose of making emergency repairs to any of the Works. Such
entry and repairing shall not be deemed an acceptance of any of the Works by the
Municipality or an assumption by the Municipality of any liability in connection
therewith or a release of the Developer from any of his obligations under this
Agreement.
SECTION 6 - DRAINAGE AND LANDSCAPE DESIGN
6.1 Drainage
All Lots and Blocks within the Plan and all lands abutting the Plan shall be graded to
drain in accordance with the Drainage Plan as approved by the Municipality's
Engineer. It is understood and agreed by the parties hereto that the drainage of surface
waters on the Lots and Blocks in the Plan, are the sole responsibility of the Developer
and subsequent purchasers, and they.shall provide and maintain adequate drainage of
such surface works. Satisfactory drainage outlets shall be provided. Drainage outlets
shall be constructed from the limits of the Subdivision to a sufficient outlet in
accordance with the approved engineering drawings.
6.2 Preservation of Trees
The Developer shall strive to preserve healthy trees, except for the actual area of
roadway construction, the installation. of services, or the areas within the building
envelope. No additional trees shall be removed without the Public Works Manager's
written permission.
52/
13
6.3 Lots Unsuitable for Building
Any lot which will require special attention in order to be serviced will be listed in
Schedule "F" of this Agreement. Prior to the issuance of a building permit for any lot
listed in Schedule "F", the Developer's 'Engineer must submit a letter to the
Municipality's Engineer outlining the measures to be taken to correct the problems on
the lots. This proposal must be approved prior to applying for a building permit.
6.4 Lot Grading
All Lands shown within the Plan shall be graded in general conformity with the Lot
Grading Plan, including fill and excavation as required for the full width and length of
the grades and levels, and to the specifications, requirements and satisfaction of the
Municipality's Engineer; provided that for residential lots and blocks, grading must be
brought within zero decimal five (0.5) metres of the final grade and such further
residential development may complete the grading. All work done by the Developer
must be of such a nature as to ensure that the integrity and intent of the overall grading
plan is functional until the Lands are fully developed.
(a) Obligation to Grade According to Lot Grading Plan
The Lands shall not be graded except in general conformity with the grades
and elevations shown on the Accepted Grading Plan. The Plan shall bear the
signature and seal of an Ontario Professional Engineer holding a Certificate of
Authorization from Professional Engineers Ontario or who is employed by a
partnership or corporation h,qlding such Certificate of Authorization to offer
professional engineering services to the pnblic (hereinafter called a
"Professional Engineer") or it Registered Ontario Land Surveyor who certifies
thereon that the Plan generllJly conforms with the Lot Grading Plan attached
to the Agreement or filed witIithe Municipality's Engineer.
(b) Certified Building Lot Site Plan
Subject to Section 8.9 herein, no building shall be constructed on a Lot or
Block within the Plan until a Building Lot Site Plan certified by a Registered
Ontario Land Surveyor or Professional Engineer has been filed with and
approved bv the Chief Building Official of the Municipality. The Building
Lot Site Plan shall show:
. the proposed finished elevation of these lands at each comer of the lot or
block;
. the proposed finished elevation of these lands at the front and rear of the
building;
. the proposed finished elevations of the underside of the footings and the
proposed finished height of the foundation of the building;
. the proposed fmished elevation of any retaining walls, the proposed
elevation of any walk-out onto these lands from the basement of the
building, and the proposed fmished height of the foundation of the
building;
. the proposed finished elevation and slope of any driveway and the
proposed location of any swale or rear yard catch basin;
. the location of eavestrough downspouts; no downspouts will be allowed to
discharge in a sideyard between residences;
. any abrupt changes in the proposed finished elevation of these lands;
. the service locations and the invert elevations of all municipal services
. the Lot and Registered Plan number, the municipal address for the subject
Lot or Block and the proposed location ofthe building thereon in relation
to the Lot or Block boundaries.
The Developer hereby agrees that the existing property line grades abutting
developed lands are not to be altered or disturbed, except as approved
otherwise by the Municipality's Engineer.
~2
14
The Developer shall complete such other actions as may be required by the
Municipality, acting reasonably, to ensure that the subdivision is developed in
accordance with the terms of this Agreement and good engineering practices.
(c) Owner's Final Grading Certificate
. The Owner's Final Grading Certificate must be completed in the form
attached as Schedule "G" bearing the signature and seal of a Professional
Engineer or Registered Ontario Land Surveyor that the actual finished
elevation and grading of these lands generally conform with the Lot
Grading Plan and the Certified Building Lot Site Plan.
. If occupancy occurs between November I and May 31 next and an
Owner's Final Grading Certificate is not filed prior to occupancy with the
Municipality's Chief Building Official, then the Owner shall provide the
Municipality's Chief Building Official with a written undertaking to file
the said Owner's Final Orading Certificate with the Municipality's Chief
Building Official by the following June 1.
. When the Owner's Final Grading Certificate is accepted by the
Municipality's Chief Building Official that the Lands generally conform
with the Lot Grading Plan and the Certified Building Lot Site Plan, the
Damage/Lot Grading Deposit referred to in Section 8.9 (h) is returnable to
the Owner subject to this Section and Section 8.9 (h) ofthis Agreement.
. The Owner agrees that, should drainage rectification become necessary in
the absolute discretion of the Municipality, and the Owner fails to make
such rectification when so instructed by the Municipality, the
Municipality may, at its option, undertake the correction of such drainage
and all costs over and above the two thousand, five hundred dollar
($2,500.00) deposit shall be charged back to the Owner and shall include
a management fee of 15% of the cost oflabour and material shall be a
charge against the Lot or Block for which regarding was carried out and
shall be payable forthwith. The Owner agrees that neither it nor its
successors or assigns will alter the grading or change the elevation or
contour of the Land except in accordance with drainage plans approved
by the Municipality.
(d) Obligation to Maintain Grading
After the building or Block is graded in accordance with the Lot Grading Plan
and the Certified Building Lot Site Plan, no change shall be made to the actual
fmished elevation and grading of the building Lot or Block in any way that
results in a material alteration of drainage on or across the building Lot or
Block or adjacent lands from that shown on the Lot Grading Plan for the
adjacent lands or the Owner's Final Grading Certificate for the building Lot or
Block.
(e) Prevention of Surface Water Flow
The Developer and each subsequent owner shall not block, impede, obstruct
or prevent the flow of surface water as provided for in the Drainage Plan, the
Lot Grading Plan or the Certified Building Lot Site Plan over any Lot or
Block by the construction, erection or placement thereon of any danuning
device, building, structure or other means.
;?3
15
(t) Erosion Control
The Developer shall construct silt fences or other facilities as required during
construction to control overland flows from this Subdivision to ensure that
mud, silt, construction debris, etc. does not adversely affect abutting
properties, all to the specifications of the Municipality's Engineer.
6.5 Maintenance of Lot Grading
All lot grading and drainage facilities and works required by Section 6 or elsewhere in
this agreement shall be provided and maintained by the Developer or subsequent owner
of each individual lot from time to time, in perpetuity at such party's sole risk and
expense.
Should, for any reason, the Developer or subsequent Owner fail to maintain that lot
grading, they acknowledge that the Municipality, in receiving certified lot grading
certificates as required in this agreement, absolves itself of any further interest or
responsibility for such lot grading save and except for those works on registered
easements.
SECTION 7 - LANDS TO BE CONVEYED
7.1 Lands for Municipal Purposes
The Developer shall convey in fee simple a good title free from encumbrances to the
Municipal lands for municipal purposes other than roads, which shall be mutually
agreed upon by the Owner and the Municipality, or to make a cash payment in lieu
thereof as stipulated by the Municipality and also to convey to the Municipality in fee
simple, the 0.3 metre reserves and other lands required by the Municipality. The deeds
for the said lands are to be approved by the Municipality's Solicitor and thereafter
forthwith registered and deposited with the CAO. The cost for preparation and
registration of the said deeds shall be paid by the Developer. A list oflands for
municipal purposes to be conveyed to the Municipality shall be set out in Schedule "H"
of this Agreement.
7.2 Easements
The Developer agrees to grant at his expense all such easements and right-of-ways as
may be required for the installation and supply of services to the Subdivision. A list of
easements and right-of-ways to be granted to the Municipality shall be set out in
Schedule "H" of this Agreement.
7.3 Turning Circles
The Municipality may require the installation of temporary turning circles. Where such
are required, the Developer shall convey the appropriate blocks to the Municipality for
the purposes of providing the Municipality with sufficient land to construct said turning
circle(s). The block(s) conveyed to the Municipality shall only constitute that portion
of land required by the Municipality for the actual roadway of the turning circle. The
temporary turning circle shall be constructed in accordance with Schedule "e" ofthis
Agreement. The Developer and the Municipality acknowledge that the block(s)
conveyed to the Municipality for turning circles shall be reconveyed to the owners in
the event that the street is connected in the future. Such conveyance and reconveyance
of the block(s) shall be completed at no expense to the Municipality. A list of said
blocks is included in Schedule "H" of this Agreement.
c?-1
16
SECTION 8 - ADMINISTRATION
8.1 Voiding Agreement
In the event that the Plan is not registered within one year from the date of the signing
of this Agreement, the Municipality may at its option declare this Agreement to be null
and void. All costs incurred shall be deducted from the deposit paid by the Developer
to the Municipality pursuant to this Agreement or any other agreement between the
Developer and the Municipality referred to herein.
8.2 Developer's Expense
Every provision of this Agreement by which the Developer is obligated in any way
shall be deemed to include the words "at the expense of the Developer" and "as
approved or accepted by the Municipality", unless specifically stated otherwise.
8.3 Phasing
(a) The Municipality may instruct the Developer to construct the Works in particular
phases suitable to it and the Developer must comply. If the Municipality does
not so instruct the Developer, before commencement of any of the Works, he
may request the Municipality's permission to divide the area into convenient
phases.
(b) If the construction of the Works is to be phased, then in lieu of furnishing
securities as required by Section 9 of this Agreement for the whole of the Works
the Developer may furnish the required securities for that part of the Works to be
constructed in each phase(s).
(c) The Land upon which the Works is to be constructed in a future phase shall be
made subject to a specific Holding Zoning ("H") provision by means of a by-law
to be passed by the Municipality under Section 36(1) of the Planning Act, R. S.
O. 1990 c. P. 13 at the Developer's expense.
(d) Prior to the commencement of the construction of the Works within the Land
made subject to a Holding Zoning ("H") provision and after the deposit with the
Municipality ofthe securities as set out elsewhere in this Agreement for such
Land along with a written request from the Developer, the Municipality shall at
the Developer's expense pass a by-law under the said Section 36 to remove the
Holding Zoning ("H") provision.
( e) Before proceeding with an additional phase the Developer shall obtain the written
approval of the Municipality and no Works shall be permitted to be installed and
no building permits issued until this approval has been given in writing by the
Municipality.
(f) Subject to Section 8.15 herein, commencement of construction within subsequent
phases of this subdivision, or other subdivisions of the Developer herein within
the Municipality, may not proceed.
8.4 Developer's Liabilities
Until the Municipality has issued the Certificate of Final Acceptance for the Works, the
Developer hereby indemnifies and saves harmless the Municipality against all actions,
causes of action, suits, claims and demands whatsoever which may arise either directly
or indirectly by reason of the Developer undertaking the Plan.
cPb
17
8.5 Insurance
The Developer shall insure against all damages or claims for damage in an Insurance
Company satisfactory to the Chief Administrative Officer (CAD). Such policy or
policies shall be issued in the jointnames of the Developer, the Municipality and the
Municipality's Engineer and the form and content shall be subject to the approval of the
Municipality. The minimum limits of such policies shall be $2,000,000 all inclusive,
but the Municipality shall have the right to set higher amounts. The said insurance
policy shall include a provision that requires the insurance company to provide the
Municipality with thirty (30) days notice of termiuation of such policy. The policy
shall be in effect for the period of this Agreement including the period guaranteed
maintenance pursuant to Section 5 of this Agreement. The issuance of such a policy of
insurance shall not be construed as relieving the Developer from responsibility for other
or larger claims, if any, for which he may be held responsible.
8.6 Legal Notice to Developer
Any notice required to be given hereunder may be given by registered mail addressed
to the Developer at his principal place of business and shall be effective as of the date
of the deposit hereof in the Post Office.
8.7 Registration
The Developer consents to the registration of this Agreement upon the title to the Land
both before and after registration of the Plan at the sole discretion of the Municipality
and at the expense of the Developer.
8.8 Mortgages/Encumbrances
The developer covenants and agrees to obtain and register, at its sole cost and expense,
a postponement from each encumbrancer with a charge registered against title to the
Land (or part thereof) so that notice of this agreement shall be registered in priority to
any such charge.
Further, the mortgagee, if any, agrees that in the event of him assigning or transferring
the mortgage on the lands, the assigoment or transfer shall be subject to the terms
hereof in the same manner as if the assignee or transferee had executed this Agreement.
8.9 Requirements for Bnilding Permits
The approval of the Plan by the Municipality or the acceptance by the Municipality of
the Works shall not be deemed to give any assurance that Municipal building permits,
when applied for will be issued in respect of the Lots or Blocks shown on the Plan.
Notwithstanding the foregoing, the Developer agrees that it, or anyone claiming titled
from it or under its authority, shall not apply for any building permits for Lots or
Blocks within the Plan until all requirements hereinafter set out have been carried out to
the satisfaction of the Municipality. It is agreed that a copy of this Section 8.9 shall be
delivered by the Developer to each and every Purchaser of Land within the Plan and to
each and every Builder obtaining a Building Permit for any Lot or Block or part of a
Lot or Block within the Plan and the Developer shall extract a covenant similar to this
covenant from all such Purchasers and Builders. The Municipality shall have the right
to refuse any such application until:
(a) Preliminary Acceptance has been granted by the Municipality for Stage I
servicing for that phase of the Subdivision.
(b) The Developer has provided sufficient documentation to the Municipality's
Engineer confirming that electrical distribution and street lighting and the
remaining underground services, telephone, cable t.v., and gas are being
scheduled for installation; and will be completed within six (6) weeks or the date
of issuance of the building permit.
.
~(p
18
(c) Approval of the Municipality has. been obtained for the construction of any
buildings to be erected on Lots or Blocks that may be listed in Schedule "F"
hereto.
(d) A certificate has been given by the Municipality's Chief Building Official that
the building location is in compliance with the zouing by-law of the
Municipality.
( e) The signs denoting "Unassumed Roads" have been installed at the entrances to
the Subdivision.
(f) All dead trees within the limit of the Plan have been removed.
(g) All street identification signs required by this Agreement have been installed and
are in place;
(h) Payment to the Municipality in the amount of $2,500.00 as a Works Damage/Lot
Grading Compliance Deposit (herein "Damage/Lot Grading Deposit") per Lot or
Block in the Plan of which the sum of$IOO.OO is non-refundable.
The balance ofthe Damage/Lot Grading Deposit shall be refundable in whole or
in part after the building has been constructed, an Owner's Final Grading
Certificate has been filed with and accepted by the Municipality's Chief Building
Official and the required service connections have been made and all damages to
the Works which form the subject matter of this Agreement resulting from house
building and/or landscaping activities on the subject Lot or Block have been
repaired to the satisfaction of the Municipality's Chief Building Official and
Municipality's Works Superintendent.
(i) With respect to repair of damage to the Works, in the event that the Owner fails to
repair the damage to the Works when so instructed by the Municipality's Chief
Building Official or the Municipality's Works Superintendent, the Municipality
may, at its option, undertake the repair of such damage and all costs over and
above the $2,500.00 deposit shall be charged back to the Owner and shall include
a management fee of 15% of the cost oflabour and material. This shall be a
charge against the Lot or Block for which repairs were carried out and shall be
payable forthwith.
G) Payment to the Municipality the amount of the current applicable Development
Charge(s) per Lot or Block in the Plan under the Development Charges By-law of
the Municipality, or The Water and Sewer Contribution to Capital Policy.
(k) A Certified Building Lot Site Plan has been filed with the Chief Building Official
of the Municipality pursuant to Section 6.4 (b).
(1) The Developer agrees that the preceding requirements in this Section 8.9 are in
addition to and not in substitution of the requirements of the Ontario Building
Code Act as amended and regulations thereunder with respect to the issuance of
Building Permits.
8.10 Requirements for Occupancy
Subject to Section 8.11 herein, no building erected on the Lots or Blocks within the
Plan shall be occupied until a Certificate ofInspection re: Readiness for Occupancy
has been issued by the Municipality's Chief Building Official and the said Certificate
shall not be issued until:
(a) Preliminary Acceptance has been granted for Stage 2 servicing for the phase of
the Subdivision including the Lot or Block.
(b) The roadway from the entrance of the Subdivision to and including the lot or
block of which the building is apart, has received the base course asphalt.
'?-7
1'9
(c) The electrical distribution plant including street lights have been installed and
approved by the Utility.
(d) The traffic and street signs have been installed and approved by the
Municipality's Engineer.
(e) Subject to Section 6.4 (c), the final grading ofthe Lot or Block is in conformity
with the overall grading plan or such variances therefrom as have been approved
by the Municipality's Chief Building Official pursuant to Section 6.4 (c).
(f) The telephone lines, cable T.V. and gas mains have been installed and approved
by the Municipality's Engineer., ,
(g) The Developer agrees that the preceding requirements in this Section are in
addition to and not in substitution of the requirements of the Ontario Building
Code Act as amended and regnlations thereunder with respect to certificates for
occupancy.
8.11 Special Building Permits / Model Homes
Pursuant to Section 8.9 building permits are not obtainable until certain services are
installed and approved by the Municipality's Engineer. The Municipality agrees that if
the Developer or Owner wishes to obtain a building permit prior to the installation of
services, as set out in Section 8.9, a permit may be issued provided the Developer or
Owner has executed a No-Occupancy Agreement (Schedule "I") and the Municipality
may require a deposit or Letter of Credit as a gnarantee of no-occupancy. In the event
that the Developer or Owner fails to meet all the requirements set out in Section 8.9 or
8.10 for any building permit that is issued pursuant to the Developer's delivery ofa No-
Occupancy Agreement, the Developer hereby acknowledges that the deposit shall be
immediately forfeited to the Municipality. Such failure to meet the obligations shall
constitute a breach of this Agreement and the Municipality may immediately draw
down any security held under this Agreement to complete any work required or fulfill
any other requirements of Section 8.9 or 8.10 for any model home that was built
pursuant to this Section 8.11.
8.12 Right to Enter into an Agreement
The Developer agrees not to call into question directly or indirectly in any proceedings
whatsoever in law or in equity any administrative tribunal, the right to the Municipality
to enter into this Agreement and to enforce each and every term, covenant and
condition herein contained and this Agreement may be pleaded as an estoppel against
the Developer in any such proceedings.
The Developer acknowledges that the Municipality is entering into this Agreement and
approving the Plan on the express representation of the Developer that it and its
successors and assigns shall observe and perform all the provisions of this Agreement
and that the Municipality is of the opinion that the Plan would not be in the public
interest if the Developer, its successors and assigns, the owner or owners from time to
time of the land within the Plan were not obligated to observe and perform all the
provisions hereof except to the extent the Municipality may lawfully change them.
8.13 Successors and Assigns
The covenants, agreement, conditions, and undertakings herein contained on the part of
the Developer shall run with the land and shall be binding upon it and upon its
successors and assigns as owners and occupiers of the said lands from time to time.
8.14 Notification to Purchaser
The Developer shall in every Agreement of Purchase and Sale or Offer to Purchase
pertaining to any Lot or Block within the Plan notifY each purchaser of all of the
payments to be made by the purchaser to the Municipality pursuant to this Agreement
and all of the provisions of this Agreement which shall continue in force after the
completion of the sale. Further, the Developer shall furnish a list of those services
included in the purchase, specifYing those installed and those to be installed at no
additional cost.
,72$
20
8.15 Scheduling, Progress and Completion
The Developer shall commence construction of services within eighteen (18) months of
the signing of this Agreement or the registration of the Plan whichever is earlier.
Within eighteen (18) months ofthe date of commencement of the servicing of any
phase, the Developer shall complete the installation of the Stage 1 services. In any
phase, the top coat of asphalt shall be completed within twenty-four (24) months of
preliminary acceptance of Stage 1 of the services; unless written consent altering this
condition is received from the Municipal Engineer. Failure to adhere to the above
schedule may result in the Municipality completing the Works in accordance with
Section 3.7 of this Agreement. If the development is phased, the date for
commencement of construction on the balance of the phases may be delayed for up to
five years. Failure to commence construction within the time schedule above may
result in the Municipality declaring this Agreement to be null and void, and the
Municipality may deem the property not to be a Plan of Subdivision.
8.16 No Municipal Liability
This Agreement and the provisions herein do not give the Developer or any person
acquiring any interest in the land within the Plan (each hereinafter in this clause called
"such person"), any rights against the Municipality or the Municipality's Engineer with
respect to the failure of the any such person to perform any obligations under this
Agreement or the failure of the Municipality to force such person to perform any
obligations under this Agreement or any negligence of any such person in the
performance of the said obligations.
The only duty and responsibility of the Municipality's Engineer arising out of this
Agreement is to the Municipality and this Agreement. Any work or services done or
performed by the Municipality's Engineer under this Agreement do not in any way
create any liability on the part of the Municipality's Engineer to the Developer or any
person acquiring any interest in the land within the Plan.
8.17 Assignment
The Developer shall not assign this Agreement without the prior written consent of the
Municipality, which consent may not be unreasonably withheld.
8.18 Conflict
In the event of any conflict between or among the plans and specifications relating to
the construction of the Works, the Municipality's Engineer shall decide which
provisions shall prevail.
8.19 Severability
If any term, covenant or provision of this Agreement shall be found or declared by a
Court of competent jurisdiction to be invalid, unenforceable or ultra vires, such term,
convenant or provision shall conclusively deemed to be severable from all other terms,
covenants and provisions of this Agreement and the remainder of this Agreement shall
be and remain in full force and effect.
8.20 Amendment
Without in any way limiting the rights of the Municipality, the Developer agrees that
the Municipality may, with the consent of the then registered owner of any land within
the Plan, amend this Agreement insofar as it specifically affects such land or any part
thereof.
.
.
c52'(
21
8.21 Further Assurances
The Developer agrees that it shall and will, on the request of the Municipality, make,
do, execute or cause to be made, done or executed all such further and other deeds acts
, ,
things and assurances to ensure the full implementation of this Agreement and to satisfY
the intention of the parties as set out in this Agreement.
8.22 Joint and Several
All terms, covenants, provisions and obligations ofthe Developer in this Agreement
shall be joint and several.
SECTION 9 - FINANCIAL PROVISIONS
9.1 Development Charges, Drainage and Local Improvement Charges
Development Charges shall be paid in .accordance with the current Development
Charges By-law of the Municipality.
The Developer agrees to pay for all arrears of taxes outstanding against the property
herein described before the approval of the said Plan is obtained. The Developer
further undertakes and agrees to pay all taxes levied on the said lands on the basis and
in accordance with assessment and collector's roll entries until such time as the lands
herein being subdivided have been assessed and entered on the Collector's Roll
according to the Registered Plan.
Before the Plan is approved the Developer agrees to commute and pay all charges made
with respect to the Drainage Act, the Local Improvement Act, and the Municipal Act,
including but not limited to charges or rates outstanding in respect of the Lands under
any sewer rate and/or water rate by-law which are assessed against the property on the
Plan. Before the Plan is approved the Developer agrees to commute and pay the
Municipality's share of any charges made under the said Drainage Act, the said Local
Improvement Act and the said Municipal Act presently servicing this property and
assessed against it.
9.2 Securities
Prior to registering this Agreement, the Developer shall deposit with the Municipality
to cover the faithful performance of the contract for the installation of the said services
and the payment of all obligations and contingencies arising thereunder the following
securities:
(a) Cash in the amount of One Hundred Percent (100%) ofthe estimated cost of the
said all works as set out in Schedule "E" and as approved by the Municipality's
Engineer and Municipal Council, or
(b) An irrevocable Letter of Credit from a chartered bank, issued in form and content
satisfactory to the Municipality's Solicitor, in the amount of One Hundred
Percent (100%) of the estimated cost of all works as set out in Schedule "E" and
as approved by the Municipality's Engineer Or
(c) Some combination of cash and Letter of Credit, totaling 1 00% of the Schedule
"E" estimate.
(d) Prior to depositing the securities, the Developer's Engineer shall submit an
estimate of the cost of the Works to the Municipality's Engineer for approval.
When the cost estimate has been approved it will be set out in Schedule "E" of
this Agreement and will become the basis for the limits of these securities.
"
~()
22
(e) All Letters of Credit shall be for a minimum guaranteed period of one (1) year or
such longer time as the Municipality may decide. All Letters of Credit referred
to in this Section 9.2 shall contain the following clause:
"It is a condition of the Letter of Credit that it shall be deemed to be
automatically extended without amendment from year to year from the present or
any future expiration date thereof, unless at least thirty (30) days prior to the
present or any fUture expiration date, we notify you in writing by registered mail
that we elect not to consider this Letter of Credit to be renewable for any
additional period. "
(f) Unless each and every Letter of Credit is renewed as noted above, the
Municipality shall have the absolute right to refuse to issue building permits and
to prohibit occupancy of homes, whether partially or fully completed, from the
said date thirty (30) days prior to the expiration of that Letter of Credit.
9.3 Reduction of Secnrities
An application for the reduction of the security on deposit with the Municipality
pursuant to Section 9.2 herein may be made no earlier than thirty (30) days after the
commencement of construction of the Works and every thirty (30) clear days thereafter.
(a) To obtain a reduction in security the Developer shall file with the Municipality's
Engineer a written application in accordance with Schedule "J" attached hereto.
(b) The application shall include written confirmation from the Developer's
Engineer:
. describing the Works constructed as at the date of the application and a
calculation of the cost thereof.
. confirming that the Works have been installed by the Developer with full
time supervision of the Developer's Engineer and in accordance with the
requirements ofthis Agreement and schedules hereto.
. describing the Works remaining to be completed as at the date of the
application and a calculation of the estimated cost thereof.
(c) The value ofthe reduction shall be determined by the Municipality's Engineer
who shall give a certificate to the CAO and the Developer confirming the amount
of the reduction of the security and the amount of the security remaining on
deposit with the Municipality.
(d) The value of the reduction shall be based upon the value ofthe Works remaining
to be completed by the Developer plus ten percent (10%) of the value of the
Works completed to the date ofthe application.
(e) Subject to any outstanding deficiencies or contingencies, the Municipality
throughout the maintenance period shall hold as security the greater of ten
percent (10%) of the estimate of the cost of the Works as set out in Schedule "E"
or twenty thousand dollars ($20,000.00).
9.4 Statutory Declaration of Accounts Paid
The Developer agrees that upon applying for a discharge of securities or for a
Certificate of Preliminary Acceptance for the services, he shall supply the Municipality
with a Statutory Declaration that all accounts for work and materials for said services
have been paid except normal guarantee holdbacks and that there are no claims for liens
or otherwise in connection with such work done or materials supplied for or on behalf
of the Developer in connection with the Subdivision.
,
$/
23
9.5 The Construction Lien Act, R.S.O. 1990 c. C.30
The Developer agrees that it will hold back in its payments to any Contractor who may
construct the services, such sums as are provided in accordance with the Construction
Lien Act, R.S.O. 1990, c. C.30, and will otherwise indemnifY and save harmless the
Municipality against any claims, actions or demands for construction liens or otherwise
in connection with the works and all costs in connection therewith, and on the demands
of the Municipality's Solicitor will forthwith take such steps to immediately discharge
all Liens upon the services.
Notwithstanding anything to the contrary contained in this Agreement, the Developer
hereby agrees that the perfecting of any liens pursuant to the said Construction Lien
Act, with respect to the land described in Schedule "A" attached hereto, shall constitute
a default by the Developer of the termS of this Agreement and shall entitle the
Municipality to draw on any or all of the security referred to in Section 9.2 of this
Agreement and to utilize said draw to make payment into Court of the holdback
together with costs.
9.6 Partial Release
Upon completion of all the requirements of this Agreement, the Municipality will
execute a partial release of this Agreement, which partial release shall be in the form
attached hereto as Schedule "K". The completion and registration of such partial
release shall constitute a full and fmal release of the obligations of the Developer, with
the exception of lot grading requirements included in Section 6 of this Agreement, as
established hereunder with respect to the lot named therein.
Notwithstanding the foregoing, the CAO shall not be required to execute a partial
release until the various services have been completed in accordance with the terms of
this Agreement and the plans and specifications provided for herein.
SECTION 10 - SPECIAL PROVISIONS
10.1 The Developer and the Municipality agree that the provisions set forth in the attached
Schedule "M" form an integral part of this Agreement.
24
~.;:z
,
SECTION 11- SIGNATURES
THIS AGREEMENT shall be binding upon and inure to the benefit of the parties hereto
and their respective heirs, executors, administrators, successors and assigns.
IN WITNESS WHEREOF the parties hereto have executed this Agreement.
SIGNED, SEALED AND DELIVERED this 19th day of September A.D. 2007
PrZt.,3tInco
( if
(Dale Walden
( IJW e have authority to bind the Corporation
(
( THE CORPORATION of THE MUNICIPALITY OF
(KIN IN
(
(
( ayor
~
(
~.At..D
~
6:---...6
IOU
bief Administrative Officer- John deRosenroll
( We have authority to bind the Corporation
Developer's Address: c/o Dale Walden, P.O. Box 351, Kincardine, ON N2Z 2Y8
Developer's Telephone: 519-395-3342
Developer's Facsimile: 519-395-3374
>
25
SCHEDULE "A" OF AGREEMENT
NOTE: It is understood and agreed that this Schedule forms part of the Municipality's
Agreement.
DESCRIPTION OF LANDS BEING SUBDIVIDED
Part of Lots A, Band C, Concession A, Geographic Township of Kincardine, Municipality of
Kincardine, County of Bruce.
(Note: This Agreement is for Lots 1-37 and associated blocks, part of File 41 T-2007.02.22).
??3
26
SCHEDULE "B" OF AGREEMENT
NOTE: It is understood and agreed that this Schedule forms part of the
Municipality's Agreement.
PLAN OF SUBDIVISION
A complete copy of the draft Plan of Subdivision prepared by Ron F. Dore, O.L.S. dated
January 12, 2007, can be reviewed at the office of the Clerk ofthe Municipality of
Kincardine.
37
3~
27
SCHEDULE "C" OF AGREEMENT
NOTE: It is understood and agreed that this Schednle forms part of the Municipality's
Agreement.
MUNICIPAL SERVICING STANDARDS
1.0 GENERAL
Service Layout Plan
A copy of the General Plan shall be submitted to the Municipality identif'ying the
proposed locations of Bell Cables, electrical servicing, gas mains, co-axial television
cables as well as watermains, storm sewers and sanitary sewers. All locations must be
established and resolved by the Developer's Engineer in conjunction with the Utility
companies and following the locations shown on the Municipality's Typical Cross-
Section.
2.0 PLANS AND DRAWING REQUIREMENTS
Plan and profile drawings must be prepared in a digital format, which is compatible with
AutoCAD Release 14, and on velum or mylar, for all new streets within the Municipality.
These digitized files and drawings, and also digitized files and drawings showing details
of special structures, etc., shall be prepared by a Professional Engineer and tumed over to
the Municipality as a permanent record prior to the acceptance of services required to be
provided by the developer.
The following standards shall be adhered to in preparation of these drawings:
(a) All profiles must be shown to the geodetic datum which is noted on each
drawings.
(b) In general, East-West streets shall have zero chainage at their Westerly limits and
North-South streets shall have zero chainage at their Southerly limits. Chainages
on Plan and Profile shall increase from left to right.
(c) Drawings shall be of a consistent size - 594 mm x 841 mm.
(d)
Scales shall be as follows for drawings:-
General Layout Plan Scale Ratio
Plan-Profile Drawings Horizontal
Vertical
or Horizontal
Vertical
Ratios shall be shown on all drawings.
- 1:1000
- 1:250
- 1:50
- 1 :500
- 1:100
( e) When the plan must be broken because of curvature, etc., the profile shall be
broken as well, so that, insofar as possible, chainage points in plan and profile
will coincide vertically.
(f) The beginnings and ends of curves must be shown on the plan and profile with
the radius of curvature shown on the plan. Chainages of points of curvature shall
be calculated.
(g) The chainage and names of intersecting streets shall he shown in plan and profile.
The drawings shall show clearly the proposed profiles, road widths and cross-
sections, ditches, ditch gradients, curb gradients if different from the proposed
services, north sign and limits of the proposed work. The plan shall show any
required off-street drainage and separate profiles shall be prepared for drainage
easements. All detail for intersecting streets including grades must be shown for
a distance of 50 metres from the intersection of the intersecting street. All street
lines, for drainage or services, shall be shown and all easements.
~0
28
(h) The Municipality shall be named.in the title block which shall be placed in the
lower right corner.
(i) On completion of the work, and prior to acceptance of the services, the drawings
shall be completed "As Recorded" and dated before turning over to the
Municipality. The Municipality shall be consulted as to the manner of showing
information not set out in these requirements. The Developer's Engineer shall
add his Professional Engineer's seal to all final drawings.
3.0 ROADS
3.1 General
All roadways shall be serviced by storm sewers and concrete curb and gutter. Road
allowances shall be a minimum of20 metres wide. The edge of the roadway paved
surface shall have a minimum radius of 9 metres at intersection. Access roads not owned
by the Municipality, leading to the area of the development, shall be maintained to a
standard equal to the standards for roadways within the development. On all streets,
horizontal and vertical sight distances and vertical curves shall meet Ministry of
Transportation (M.T.O.) requirements.
Street allowances on cul-de-sacs are to have a minimum radius of 20 metres. Edge of
pavement radius on cul-de-sacs are to be a minimum of 13 metres.
Minimum road asphalt width shall be 8.5 metres. The finished roadways shall have a
crossfall of 2% from the centerline to each curb line, and the boulevards shall have a
finished crossfall of a minimum of 2% and a maximum of 8% from the top of curb to
back of boulevard, draining towards the curb.
3.2 Clearing and Grubbing
Trees shall be removed so that the specifications for sight distances, grading, ditching,
etc., may be met. All stumps, logs, brush, boulders, debris, etc. shall be removed from
the entire street allowance. Unless noted otherwise, all healthy trees not obstructing
visibility or installation of services shall be preserved. The Municipal Engineer may give
special permission to leave trees on the street allowance, providing that they are situated
more than 1.5 metres behind the curb.
3.3 Grading
A 2 metre boulevard area behind the curbs shall be graded at a minimum of 2% towards
the curbs. The area from the edge of the road boulevard to the street line shall be graded
with a side slope not exceeding a slope of 3 metres horizontal to 1 metre vertical to meet
the original ground. All side sloped ditches and boulevards to the street line shall be
protected with nursery sod over a minimum depth of 100 rom of topsoil.
3.4 Road Construction
All road construction shall conform to applicable standards of the Ontario Provincial
Standard Specifications (OPSS) and the Ontario Provincial Standard Drawings (OPSD).
The granular roadbase shall consist of a bottom course of 300 rom minimum depth
consolidated Granular "B" full width across the roadway and a top course of 150 rom of
Granular "A" full width between concrete curbs. The granular materials shall be spread
in layers of ISO rom maximum compacted depths, and each layer shall be thoroughly
compacted. No granular base of surface material shall be placed until the grade on which
it is to be laid has been inspected and approved by the Municipal Engineer. During and
between construction seasons, the granular base shall be maintained suitable for vehicle
and pedestrian traffic, including dust control by calcium chloride and renewed if required
to the satisfaction of the Municipal Engineer.
Road subdrains shall be provided in accordance with OPSS 405.05. The subdrain shall
include filter wrap (non-woven type) Class 1 and F.O.S. Of 130 - 100.
~?
29
3.5 Roadway Surface Asphalt
As soon as the granular base has been completed, it shall be thoroughly compacted and
shaped and the base course of asphalt placed. The base course shall consist of 50 mm
minimum thickness of HL-4 Base Course Asphalt. The surface coat of asphalt may be
placed upon the approval of the Municipal Engineer which shall not be given for at least
one year from the date of placement of the base course of asphalt or until 50 percent of
the houses have been constructed. The surface course asphalt shall consist of 40 mm
minimum thickness ofHL-3 Surface Course Asphalt. Asphalt work shall conform in all
respects to OPSS 310.
3.6 Curbs
Concrete curb and gutter, of cross-section approved by the Municipal Engineer, shall be
provided along all edges of paved roadway surface. Terminations at the limits of the
subdivision shall be either joined to existing concrete curbs or rounded to reduce hazard
to traffic. Construction shall conform to OPSS 353.
3.7 Accessibility
As part of construction of any concrete curb and gutter, sidewalks or other surface
structures, the Developer will be responsible for construction in accordance with the
Municipality's current accessibility standards to provide full access where possible, to all
individuals in the community.
3.8 Driveway Aprons
The Developer will provide at each driveway, or will cause to be provided by subsequent
Owners, a driveway apron from the back of the curb to the face of the sidewalk or where
there is no sidewalk, to the limit of the property line. This driveway apron should be hard
surfaced with either 50 mm of asphalt pavement or a minimum of 100 mm of concrete
pavement over the granular base, consisting of a minimum of 100 mm of granular "A"
and 200 mm of granular "B". Alternatives to these surfaces may be considered subject to
the approval ofthe Municipality.
3.9 Turning Circles
Where construction is phased, the Municipality may require the installation of temporary
turning circles. These turning circles will be constructed in accordance with the
requirements for cul-de-sacs in Section 3.1 of this Schedule. Elsewhere in the Agreement
are provisions for conveyance of blocks for the construction of said circles.
4.0 STORM DRAINAGE/STORMWATER MANAGEMENT
4.1 Approval of Design and Plans
Storm sewers shall be provided to serve the whole ofthe subdivision. Drawings shall
consist of an overall plan, a plan and profile of each storm sewer, drawn to the same scale
as the roads, pipe bedding, manholes, and other appurtenances. Desigu of the proposed
works must be submitted to the Municipal Engineer and applicable government agencies
for approval. Plans of the entire systenJ. shall be submitted to the Ministry of the
Environment for approval. Approval for construction will not be given until the
Certificate of Approval for the sewers has been received from the Ministry of the
Environment and all other applicable government agency approvals has been received.
3g
30
4.2 Stormwater Management Report
A Stormwater Management Report setting out the existing and proposed drainage pattern
together with a Lot Grading Plan and an Erosion and Sediment Control Plan shall be
submitted to and approved by the MQIlicipal Engineer, the local Conservation Authority
and the Ministry of the Environment.
The stormwater management requirements within the Municipality shall be those of the
local Conservation Authority or as listed below. The general requirements are as follows:
. Quality and quantity control- as dictated by the local Conservation Authority and
MOE requirements in accordance with the MOE "Stormwater Management Practices
Planning and Design Manual" or the most recent version thereof. Quantity control
shall restrict post-development runoff flows to pre-development flows between the 5
and 100 year events.
· The design storm for the minor systems shall be the 5 year storm for local storm
sewers and the I 0 year storm for trunk facilities.
· Sediment and erosion control measures associated with the stormwater management
requirements shall be identified on the drawings for works to be included during the
construction and for permanent measures.
4.3 Connection to Municipal System
The storm sewers shall be connected to the Municipal storm sewer system or discharged
to a natural watercourse as approved by the Municipality and the Ministry of the
Environment.
4.4 Design Criteria
The stormwater management system shall be designed by using MIDUSS version 4.72.1
or an alternate approved hydrologic model. The Developer's Engineer shall consult the
Conservation Authority as to the appropriate storm distribution and duration to be used.
The Developer's Engineer shall advise the Municipal engineer in writing as to the
Authority's requirements. The minor system (storm sewer) shall be designed to convey
the 5 year design storm, while the major system shall be designed to convey the 100 year
design storm. Post-development runoff flows shall be controlled to pre-development
levels for rainfall events with return periods between 5 and 100 years. The design of the
stormwater management system shall be in accordance with the newest version of the
"Stormwater Management Practices, Planning and Design Manual", as prepared by the
Ministry of the Environment.
4.5 Location
The storm sewer shall be located within th.e street, with lateral connections to catch basins
located along the gutter lines.
4.6 Sewer Pipe Material
Sewer pipe material shall be Concrete Pipe, or approved alternate, complete with rubber
gasket connections Class CI4 ES or reinforced concrete pipe of the class required for the
depth of cover. The minimum size, including catch basin leads, shall be 300 rom. The
Municipality may require a larger storm sewer size on parts of the subdivision than
required for the subdivision alone.
~!
31
4.7 Storm Sewer Construction
Storm sewer construction and pipe bedding shall conform to the requirements of the
Ontario Provincial Standard Specifications for sewer construction. Pipes shall be bedded
in approved granular materials.
Catch basin leads shall be connected to the main sewer with a manhole except where the
main sewer size exceeds 450 mm diameter, in which case the lead can be connected
directly to the main sewer using a factory mannfactured "Tee".
4.8 Manholes and Catch Basins
Concrete manholes shall be provided at all changes in direction of the sewer and at all
street intersections, but no further apart than 120 m. Manholes shall be 1200 mm
diameter or larger, conforming to opsb Series 700. Benching shall be provided in all
manholes. Catch basin manholes shall contain a sump or minimum depth of 300 mm
below lowest invert on sewers up to and including 450 mm diameter.
Frames and covers shall be OPSD 401.01 Type A, or approved equal, set on not less than
three (3) layers nor more than six (6) layers of brick which shall be parged on the outside
face.
Catch basins shall be provided on both sides ofthe street at all low areas but no further
apart than 90 m. Catch basins for depth up to 2 m from ground level to invert shall be
600 mm square concrete conforming to OPSD 705.01. For greater depths, catch basins-
manholes shall be used conforming to OPSD 701.03.
4.9 Private Drain Connections
Private drain connections to the storm sewers shall be provided for each residential unit.
A 100 mm diameter connection suitable for receiving pumped sump flow from footing
drains will be placed at a depth of 1.4 metres at the property line on each lot.
5.0 SANITARY SEWERS
5.1 Approval of Plans
Plans of the entire system shall be submitted to the Ministry of the Environment and the
Municipal Engineer for approval. This submission shall consist of an overall plan, a plan
and profile of each main sewer drawn to the same scale as the roads, together with typical
details of house service connections, pipe bedding, manhole covers, all special bends and
connections and other appurtenances. Approval for construction will not be given until
the Certificate of Approval for both sewers and sewage treatment facilities has been
received from the Ministry of the Environment.
5.2 Location
The main sewers shall be located along the centre of the street allowance. House
connections shall terminate at the property line at the centre of each lot.
5.3 Material
Main sewers shall be P.V.C. or approved alternate. House connections shall be P.V.C. or
approved alternate. All joints shall be of the rubber gasket type as approved by the
Municipal Engineer. Approved caps shall be provided for service lateral terminations.
5.4 Size
The minimum size for main sewers shall be 200 mm diameter. House connections shall
be a minimum of 125 mm in diameter. For multiple dwelling, industrial or commercial
buildings, the service connectious shall be sized to accommodate the flow.
~()
32
5.5 Sanitary Sewer Construction
Sewer construction and pipe bedding shall conform to the requirements ofOPSS 410 for
sewer construction. A minimum 2.0 metre depth of cover shall be provided over all
sanitary sewers and service laterals.
5.6 House Connections
Plan locations and invert elevations, for all house connections at the street line, shall be
shown on the drawings. Minimum fall on house connections shall be 2%; maximum 8%.
Where the depth of sewer is excessive, a riser may be used over the main sewers. Shop
manufactured "Tee" connections shall be used for house connections to the main sewer.
A cap of approved manufacture shall be installed on each service lateral termination at
the street line and made watertight. The ends of all services shall be marked by a 50 mm
x 100 mm wood post extending from the service to 300 mm above the surface of the
ground and the top section painted fluorescent green. Connections to manholes shall
enter the manhole no higher than 0.5 m above the lowest invert, except as otherwise
approved by the Municipal Engineer.
5.7 Manholes
Concrete manholes shall be provided at all changes in direction of the sewer and at all
street intersections, but no further apart than 120 m. Manholes shall be 1200 mm dia.
Conforming to OPSD 701.010. Benching shall be provided in all manholes.
5.8 Testing and Flushing of Sewers
The complete sewer system, including hpuse connections, shall be tested and flushed in
accordance with OPSS 410, including the requirement for camera inspections. The
Developer shall arrange the tests for sections of sewer between manholes and shall inform
the Municipal Engineer when a section is on test and ready for inspection. Any sections
of sewer which fail to meet the requirements of this section shall be repaired and retested.
5.9 Completion and Acceptance
The complete sewage collection system installation must be approved by the Municipal
Engineer prior to the issuance of building permits for the subdivision.
6.0 WATERMAINS
6.1 Approval of Plans
Plans of the entire system shall be submitted to the Ministry of the Environment and the
Municipal Engineer for approval. This submission shall consist of an overall plan, a plan
and profile of each watermain drawn to the same scale as the roads, together with typical
details of house service connections, pipe bedding and other appurtenances. Approval for
construction will not be given until the Certificate of Approval for the watermain system
has been received from the Ministry of the Environment.
6.2 Locations
Watermain: The watermain shall typically be installed within the boulevard of the
street, in accordance with the Municipality's Typical Cross-Section.
Service Lines: In general, house services shall not be installed in driveways. Where the
driveway location is unknown at the time ofwaterrnain construction,
service connections shall terminate at the property line at the centre of
each lot.
Main Valves: To be located at the extension of property line, where the valve is being
installed at intersections.
r//
33
Curb Stops: To be provided for each service connection and to be located at the lot
line.
6.3 Connection to the Municipal System
In general, the watermains shall be looped to existing municipal systems.
6.4 Material and Size
Watermain:
Gate Valves
and Boxes:
Fittings:
Hydrants:
Services:
Watermain material shall be Polyvinyl Chloride PVC-C-900 Class 150
(DR-l 8). Pipe joints shall be bell and spigot with rubber gaskets.
Valves shall be resilient seated gate valves. Main line valves to be MJ
type with standard operating nut. Hydrant valves to be MJ to MJ gate
valve with standard operating nut.
All valves to be supplied with "0" ring packing for water use and open
counter-clockwise.
Valve boxes shall be Canada Valve screw type with No.6 base.
Tapping valves and sleeves must meet with approval of the Operating
Authority.
Resilient-seated gate valves shall be in accordance with A WW A C509
All fittings shall be ductile iron cement mortar lined mechanical joint
(MJ) type with adaptors to suit other materials, where necessary. All
fittings must be suitably thrust blocked using concrete thrust blocking as
per OPSD 1103.010 or 1103.020. A polyethylene barrier shall be used to
prevent a bond between the fitting and the concrete.
Ductile iron fittings shall be in accordance with A WW A ClIO and the
rubber-gasket joints for ductile iron fittings shall be in accordance with
AWWA Clll, pressure rating 1035kPa.
Fire hydrants shall be the Mueller Canada Valve New Century type or
approved McAvity equivalent. Hydrant specifications as follows:
. 2-64 mm hose connections
. B pumper connection
. Hydrants shall open counter-clockwise
. Colour shall be REJ)
. Operating nut shall be standard
. Hydrant length shall be such that the bottom of the upper barrel shall
be 100 mm above finished grade
. Bury depth 1.7 m.
Dry-barrel fire hydrants shall be in accordance with A WW A C502.
Min. 19 mm, Max. 50 mm
. Corporation stops - Mueller, C.C. thread inlet! compressionjoint
outlet.
. Curb Stop - Mueller, compression joint inlet! compression joint outlet
or approved equivalent.
. Pipe - to be 19 mm Type "K" copper tubing.
. Service Boxes - Model No. D-l by Concord-Clow or Mueller
equivalent. Service box and stem (1.4 m to 1.7 m) with 25 mm dia.
steel upper section. Box lids shall be regular ribbed with brass
pentagon plus c/w standard stationary rod.
. Service saddles - Model No. 2616 by Robar Industries Inc., stainless
steel, double bolted, broad band.
"'12
34
Underground service line valves and fittings shall be in accordance with
A WW A C800.
Model numbers shall be stamped on all valves and materials.
Anodes: 5.5 kg; zinc casting with a galvanized steel core, packaged in a cardboard
or cloth bag of minimum diameter of 100 mm. Gypsumlbentonite backfill
material (electrical resistivity <50 ohm cm wet). Insulated copper wire
brazed to core wire.
Tracer Wire: All PVC watermain to be provided with a No. 10/7 strand copper cable
having TWH insulation.
6.5 Watermain Construction
All watermain and appurtenances to be installed, bedded and backfilled in accordance
with current Ontario Provincial Standard Specifications and to the satisfaction ofthe
Municipality.
Minimum 1.7 metre depth of cover over all mains and services.
Main valves and hydrant sets shall, generally, be located at a maximum spacing of 200
metres and 120 metres, respectively.
At main intersections, a main valve shall be provided at each direction from the
intersection, less one.
Zinc anodes to be supplied and installed on services.
6.6 Flushing, Testing and Disinfection
All watermain shall be tested, flushed, swabbed and disinfected. Such procedures shall
be in accordance with OPSS 701 for pressure testing and A WW A C651-99 for
disinfection and connection to the waterworks system. The Developer shall inform the
Municipal Engineer when the watermain is to be tested and disinfected. Bacteriological
testing will be completed by the municipal operating authority. The Developer will be
billed for any testing or retesting required. Any failure of the testing and disinfecting
shall require the Developer to reflush, retest and/or redisinfect the watermain until the
watermain has met the requirements of the Ontario Provincial Standard Specifications
and the MOE, to the satisfaction ofthe Municipality.
6.7 Completion and Acceptance
The complete water distribution system installation must be approved by the Municipality
prior to the issuance of building permits for the subdivision.
7.0 SIDEWALKS
A 1.5 metre sidewalk shall be constructed on one side of each street within the
development. Sidewalks shall have a minimum depth of 125 mm and shall be bedded in
granular in accordance with the currept OPS standard details.
/1_3
3.5
8.0 UTILITIES AND STREET LIGHTING
8.1 Telephone
Telephone service shall be underground and shall be installed by B.M.T.S. or Hurontel.
The Developer must bear the cost of any surcharges for underground installation made by
the Utility and must grant the Utility any easements for their services.
8.2 Electrical
Underground electrical installation shall be completed to the satisfaction ofthe local
power supplier based on their most current specification.
8.3 Cable T.V.
Developers shall arrange to have Cable T.V. installation completed by the local supplier.
8.4 Street Lighting
The minimum standard for street lighting shall be 100 watt High Pressure Sodium Lamps
set on 9 metre poles, or as directed by the Municipality. Each light must be controlled by
a dusk to dawn photo-electric cell. Power feed shall be completely underground. The
lights shall generally be placed to the outside of curved roads. The maximum allowable
spacing along the street between the lights shall be 50 metres but may be increased, at the
Municipality's direction, to a maximum of75 metres (in special instances). The poles
must be installed at the location as shown on the Municipality's Typical Cross-Section.
Particular care shall be taken to adequately illuminate the intersections and cul-de-sacs.
9.0 LOT GRADING
9.1 Honse Lot Grading
Generally, all lots shall be excavated or filled so that the whole of the lot area from the
street line to a line at least 3 metres beyond the rear of the building shall have an
elevation not less than 0.5 metres or more than 2 metres higher than the fmished crown of
the road opposite the centre of the lot. In situations where the slope of the land justifies
different requirements, the Municipal Engineer may permit variations of the above. A
plan showing proposed lot grades and house floor levels shall be submitted to the
Municipal Engineer for his approval, and the Engineer retains the right to amend any of
the grades proposed if the Engineer considers a particular situation so warrants.
10.0 LANDSCAPING
Boulevards along each street shall be topped with a minimum of 100 mID oftopsoil.
Seeding shall be completed in all boulevard areas.
A tree shall be planted in the boulevard in front of each lot within 1 year of the date of
completion of the Stage 2 services. Trees shall be 60-70 mID diameter measured 500 mID
above the ground. All trees shall be No. I nursery stock. The type of trees shall be
approved by the Municipality. These shall be staked to Municipal specifications. Trees
shall be watered at the time of planting and every two weeks thereafter and the Developer
shall warrant trees for a period of one year from the date of planting. Planting shall be
limited to the spring and fall seasons.
/j~
36
11.0 EROSION CONTROL
During construction the Developer shall ensure that surface runoff from the lots and
blocks as well as the roadways is protected from erosion by the use of silt fences, straw
bales and other measures designed to minimize such erosion. Temporary outlets at
culverts or catch basins shall be checked to prevent silts from entering into storm sewers
or water courses. Such erosion control measures shall be shown on the drawings for
approval by the Municipal Engineer and the Conservation Authority.
12.0 WALKWAY
All walkways shown on the plan of subdivision shall be constructed by the Developer.
Walkways shall be constructed of a 150 mm minimum depth of Granular "A" on a
properly constructed foundation and shall be paved with a concrete sidewalk to a
minimum width of 1.5 metres and a minimum depth of 125 mm.
A standard 1.5 m high chain link fence shall be placed along both sides ofthe right-of-
way with posts placed at each end to prevent vehicular traffic from using the walkway.
13.0 PARKLAND IMPROVEMENTS
The area of land deeded to the Municipality for Public purposes, other than highways,
shall be carefully graded, care being taken to preserve any trees. The whole area shall be
top dressed with a minimum of 100 mm of topsoil and shall be seeded with approved
lawn seed mix (OPSS 572).
The Municipality may ask and provide details within this agreement for additional
Parkland improvements as might be warranted.
14.0 TRAFFIC AND STREET SIGNS
14.1 Proposed street names shall be subject to the approval of the Municipality
14.2 Street Name Signs and House Numberiug
At each intersection there shall be erected an approved double unit street name sign. The
signs and posts will be provided by the Municipality at the Developer's expense.
14.3 Traffic Signs
Traffic signs and posts will be provided by the Municipality at the Developer's expense,
following the passing of a by-law for their installation.
14.4 Guide Posts
On Fills higher than 2 metres, timber guide posts or guard rails shall be installed
conforming to OPSS and OPSD Standards.
15.0 PAYMENT TO SUBDIVIDERS
The Municipality shall not be liable for any costs arising out of the construction of
services except under the following conditions.
a) Where a storm sewer is larger than required, the Municipality may pay the
difference in cost for supplying the larger size pipe and any additional manholes
required for completion of the system.
.
37
b) When a sanitary sewer in excess of 250 nnn diameter is required, for lands outside
the subdivision, the Municipality may pay the difference in cost for the supply of
the larger size pipe.
c) When a watermain in excess of200 nnn diameter is required, for lands outside the
subdivision, the Municipality may pay the difference in cost for the supply of the
larger size pipe and fittings.
16.0 TYPICAL ROAD CROSS SECTION
A typical urban road cross section is attached.
/iZ?
~
~
I~ORTH OR WEST
STREET LINE
1/)
h
FUTURE 1.5 cmJc.
SIDEWALK (WHERE
REQUIRED)
1.0
)f \~
\
S/w 2~ ^,-rjt~,
-7'"
.0- r~...
::;;0 II Z
GAS '"
(FUTURE) II '"
0.5 U
3.0 .1
PRIMARY AND SECONDARY
HYDRO, BELL &. CABLE TV.
4.0
'- ROW
10.0
10
4.25
I CONe CURB AND GUTTER
O.P.S.D 600.100
(BOTH SIDES)
-2%
!~i
'1I~' 'i'~ :
::"-.;:: .:,.,.,"....; ,.1 :~;,
.... :.":.~
.,.r.-., _, ,"hl ",.i!' ~
/;/
/; ,/
-3%
((
II
II
II
II
IL
L_
150mm GRAt.J. 'A'
.300mm MIN. GRAN, 's'
10.0
'- CB.
C~~
4.25
1.0
HL-J ASPHALT SURFACE
HL-4 ASPHALT B~,SE
2~ ---
0.10 TOPSOlL
AND SOD
B% MAX.
:.,.;,,:.,
/
;f~
C!~
~ ~
':':'::"'\:1 '":"'-'1>1.' ".'"
/
/
/'/
3%_ I
CA'1CH BASnJ --I L J I
L_:'J
STORM SEWER
WAlERMAI~J - I
()-- SANITARY SEWER
PRIMARY Al'JD SECONDARY
HYDRO, BELL & CABLE TV.
4.55
N01FS:
1. TOPSOIL 10 RE~O'oED TO 115 FULL DEP'Di ALONG ENTIRE YllDTH OF ROAD B~ CURBS.
2. BOULEVARD TO BE FULLY SODDED AS SPECIFIED.
3. ROAD CROSSINGS DEP'Di5 FOR UTlUlIES - HYDRO 1.2 MIN.
- BEUL TELEPHONE. UNION GAS, CABLE TV 1.0 MIN.
- WATER 1.7 MIN.
~. ALL WA'fER SER'IICE BOXES TO BE SET AT PROPERTY UNE.
5. ROAD RECONSlRUClION DESIGN TO BE CONFIRMED BY GEOTECHNICAL DESIGN
@ i<i)\fC.A'~IN[
~fll'l' .tmNg~ bohmr...rllihl'
2..5
l
4.25
Municipality of
Kincardine
Typical 20 meter Urban Subdivision
Sec:llon and Service locations
Local Residential Streets
SOUTH DR EAST
STREET ur~E
FuruRE '.5 CONe.
SIDEWALl< (WHERE
REQUIRED)
1.0
@
S/W
'" .
e. L
d~
0.5
GAS
(FUTURE)
3.0
4.0
DATE OF REVISION. April 21, 2005
@!rm~!.!
//1
39
SCHEDULE "D" OF AGREEMENT
Note: It is understood and agreed that this Schedule forms part of the Municipality's
Agreement.
CHECKLIST OF WORKS TO BE CONSTRUCTED
1. Road restoration, complete with asphalt paving and curb and gutter Ii'!
2. Storm Water Management Plan, storm sewer system, modifications and
private drain connections. Ii'!
3. Sanitary sewers building connections to the lot line Ii'!
4. Water distribution system building connections to the lot line Ii'!
5. Grading and requirements of a site grading plan Ii'!
6. Underground electrical service Ii'!
7. Utility obligations - telephone, cable t.v. Ii'!
8. Sidewalks Ii'!
9. Topsoil and sod on boulevard from property line to curb Ii'!
10. Lot house number signs. Ii'!
Note: Works Required Denoted by Ii'!
40
.1ft
SCHEDULE "E" OF AGREEMENT
Note: It is understood and agreed that this Schedule forms part of the Municipality's
Agreement.
ITEMIZED ESTIMATE OF COSTS OF CONSTRUCTION
OF EACH PART OF THE WORKS
Road Works
Water Servicing
Sanitary Servicing
Drainage Works
Electrical
Subtotal
134,000
99,300
68,200
180,000
77.700
559,200
Engineering
Subtotal
GST (6% rounded)
28.000
587,200
35.300
$622,500
41
SCHEDULE "F" OF THE AGREEMENT
Note: It is understood and agreed that this Schedule fOTITIS part of the Muuicipality's
Agreement.
LIST OF LOTS UNSUITABLE FOR BUILDING PURPOSES - CLAUSE 6.3
None
47
,1>0
42
SCHEDULE "G"OFTHEAGREEMENT
NOTE: It is understood and agreed that this Schedule forms part of the Municipality's
Agreement.
OWNER'S FINAL GRADING CERTIFICATE
The undersigned hereby certifies to the Corporation of the Municipality of Kincardine (the
"Municipality") that the foundations of the buildings and structures and any openings in any such
foundation walls constructed on the following property:
STREET NO.
STREET
MUNICIPALITY
LOT/BLOCK
REGISTERED PLAN NO.
Have been constructed, at or above the elevations illustrated on the overall Certified Building
Lot Site Plan (as approved by or on behalf of the Municipality) referred to in the Agreement
registered against the title to the above property as shown on the as-built gradiug survey
attached.
The undersigned further certifies to the Municipality that:
I. The final grading of the above referred to property has been completed in substantial
compliance with the Certified Building Lot Site Plan referred to in the Agreement.
2. The grade elevation of all lot boundaries and corners including the front lot corners of the
property are in substantial compliance with the Certified Building Lot Site Plan; and
3. The above lot has been graded to provide positive drainage in the front, rear and sideyard and
that there is no area of the property which is subject to ponding of water; and
4. That in all cases, the final grading conforms to the intent of the grading plant.
This certificate is given and delivered to the Municipality in full knowledge that the Municipality
relies on this certification in providing a release of the applicable Agreement affecting this
property.
DATED at
, Ontario this
day of
,200_.
Signature ofOLS/Professional Engineer
NOTE: Copies of this Owner's Final Grading CertifICate are available at the Municipality's
Building Department.
~-)
43
SCHEDULE "H" OF AGREEMENT
NOTE: It is understood and agreed that this Schedule forms part of the Municipality's
Agreement.
LANDS FOR MUNICIPAL PURPOSES TO BE CONVEYED TO THE MUNICIPALITY
Block 98 (or such block as may be renumbered between Lots 24 and 25.
LIST OF EASEMENTS TO BE GRANTED TO THE MUNICIPALITY
Easements for rear yard catch basins between Lots 5 & 6, 10 & 11, and 14 & 15.
g;-":2-..
44
SCHEDULE "I" OF AGREEMENT
NOTE: It is understood and agreed that this Schedule forms part of the Municipality's
Agreement.
NO OCCUPANCY AGREEMENT
NOW THEREFORE THIS AGREEMENT WITNESSETH that in consideration of other
good and valuable consideration and the sum of One ($1.00) Dollar oflawful money of Canada,
the Parties hereto mutually covenant and agree as follows:
1. In consideration of the Corporation of the Municipality of Kincardine issuing a building
permit to the Owner for
, the Owner
covenants and agrees that it will not apply for an occupancy permit until the above
referred to services have been installed to the satisfaction of the Municipality;
2. The Municipality hereby acknowledges that it has a cash deposit from the Developer in
the sum of and will use its best efforts to see to it that the
above referred to services are completed by
THIS AGREEMENT shall be binding upon and enure to the benefit of the parties hereto
and their respective heirs, executors, administrators, successors and assigns.
IN WITNESS WHEREOF the parties hereto have executed this Agreement.
SIGNED, SEALED AND DELIVERED
This day of , 200 _.
(
(
(
( DEVELOPER (NAME OF DEVELOPER)
(
( THE CORPORATION OF THE
( MUNICIPALITY OF KINCARDINE
(
(
( Mayor
(
(
( CAO
( We have authority to bind the Corporation.
53
45
SCHEDULE "J" OF AGREEMENT
Note:
It is understood and agreed that this Schedule forms part of the Municipality's Agreement.
APPLICATION FOR REDUCTION OF SECURITY
To:
(Name of Municipality's Engineer), Engineer, Municipality of Kincardine
Developer:
(Name of Developer)
Agreement:
(Date of Agreement)
Property:
(Legal Description of Property)
Application No.
(Specify number of application)
The undersigned, (Name of Developer's Engineer) being the Developer's Engineer, hereby
confirms that the Works constructed as at the date of this Application have been installed by the
Developer under the full time supervision of the Developer's Engineer and in accordance with
the requirements of the Agreement between the Developer and the Municipality.
The Works installed to the date hereof and the calculation of the cost thereof are detailed in the
schedule attached hereto.
Further, the undersigned Developer's Engineer hereby confirms that the Works remaining to be
constructed as at the date of this Application and the calculation of the estimated cost thereof are
also detailed in the schedule attached hereto.
This Application is given and delivered to the Municipality's Engineer with full knowledge that
the Municipality's Engineer and the Municipality will rely upon the information contained herein
in granting a reduction of the security held by the Municipality pursuant to Section 9.2 of the
said Agreement affecting the above property"
DATED at
, Ontario this
day of
,200_"
Signature of Developer's Engineer
Name of Developer's Engineer
::>-i
46
SCHEDULE "K" OF AGREEMENT
NOTE: It is understood and agreed that this Schedule forms part ofthe Municipality's
Agreement.
FORM OF PARTIAL RELEASE:
PARTIAL RELEASE
IN FAVOUR OF:
Herein called the "Owner"
WHEREAS the Owner entered into certain obligations in favour of the Corporation of the
Municipality of Kincardine under an Agreement registered against the lands hereinafter
described as Instrument No.
AND WHEREAS the Owner has satisfied and fulfilled all of those obligations.
NOW THEREFORE the Corporation of the Municipality of Kincardine releases the Owner from
the obligations contained in the said Agreement, with the exception of the lot grading provisions
in Section 6.5 in said Instrument No. _, as amended, and certifies that all other provisions of
that Agreement, as amended, are no longer binding with respect to the said lands. The lands
released hereby are:
ALL AND SINGULAR that certain parcel or tract ofland and premises situate, lying and being
in the Municipality of Kincardine ( ), County of Bruce and being composed of Lot
_ Registered Plan -' the Municipality of Kincardine has, by Bylaw ,
registered in the said registry office as Instrument No. , provided that this Partial
Release shall be executed by the CAO and sealed with its seal.
DATED this
day of
,20_
47
,-
t?--:<'
SCHEDULE "L" OF AGREEMENT
NOTE: It is understood and agreed that this Schedule forms part of the Municipality's
Agreement
CONDITIONS OF DRAFT APPROVAL
The Conditions of Draft Approval for File No.
Bruce as attached hereto.
for the Corporation of the County of
CONDITIONS OF DRAFT PLAN Of SUBDIVISION APPROVAL
Owner:
FileNo:
Municipality:
Subject Lands:
1582679 Ontario Inc., c/o Kelden Developments
41T-2007,02.22
Municipality of Kincardine
Part of Lots A, 8, and C, Con A, Municipality of Kincardine (former
Town of Kincardine)
June 22, 2007
Date of Draft Approval:
The Approval Authority of the Corporation of the County of Bruce hereby issues Draft Approval to
Subdivision File No. 41T-2007-02.22, which pertains to Part of Lots A. B, and C, Con A, Municipality
of Kincardine (former Town of Kincardine).
The following conditions have been established by the County of Bruce and must be
met prior to the granting of final approval:
No.
ConditIon
Identification
1. That this approval applies to Plan of Subdivision File 417-2007.02.22 for 1582679
Ontario Inc., c/o Kelden Developments Part of Lots A. B, and C, Con A, Municipality of
Kincardine (former Town of Kincardine) prepared by R.F. Dore Surveying Limited
(Project No, 30469-Revision #3) dated 2007.01.10.
Public Roads and Walkwavs
2. That the road allowances shown on this Plan of Subdivision shall be dedicated on the
finat plan as a public highway to the appropriate road authority.
3. That the street(s) shall be named to the satisfaction of the Municipality of Kincardine.
4. That any dead ends and/or open sides of road allowances created by this Plan of
Subdivision shall be terminated in 0.3 metre reserves to be conveyed to and held, in
trust, by the Municipality of Kincardine until required for future road allowances or the
development of adjacent land.
Parkland/Ooen Space
5. That the owner conveys land in the amount of 5% of the land included in the Plan to the
Municipality of Kincardine for park purposes pursuant to the provisions of Section
51(5)(a) of the Planning Act R.S.O. 1990 c.P.13. Alternatively, the Municipality of
Kincardine may accept cash-in-Iieu of the said conveyance and under provisions of
Section 51(8} of the Planning Act, R.S.O. 1990 c.P.13 the Municipality of Kincardine is
hereby authorized to do so.
Subdivision Aareement
6. That the owner enter into an agreement with the Municipality of Kincardine to satisfy all
the requirements, financial and otherwise, of the municipality concerning the provision of
roads, installation of services, facilities and drainage.
47
~6
,
.'
SCHEDULE "L" OF AGREEMENT
NOTE: It is understood and agreed that this Schedule forms part of the Municipality's
Agreement.
CONDITIONS OF DRAFT APPROVAL
The Conditions of Draft Approval for File No.
Bruce as attached hereto.
for the Corporation of the County
CONDITIONS OF DRAFT PLAN OF SUBDIVISION APPROVAL
Owner:
FileNo;
Municipality:
Subject Lands;
1582679 Ontario Inc., c/o Kelden Developments
41T-2007,02.22
Municipality of Kincardine
Part of Lots A. B, and C, Con A, Municipality of Kincardine (former
Town of Kincardine)
June 22, 2007
Date of Draft Approval:
The Approval Authority of the Corporation of the County of Bruce hereby issu es Draft Approval to
Subdivision File No. 41T-2007-02.22, which pertains to Part of Lots A, B, and C, Con A, Municipality
of Kincardine (fanner Town of Kincardine).
The following conditions have been established by the County of Bruce and must be
met prior to the granting of final approval:
No.
Condition
Identification
1. That this approval applies to Plan of Subdivision File 41T-2007.02.22 for 1582679
Ontario Inc., c/o Kelden Developments Part of Lots A, B, and C, Con A, Municipality of
Kincardine (former Town of Kincardine) prepared by R.F. Dare Surveying Limited
(Project No. 30469-Revision #3) dated 2007.01.10.
Public Roads and Walkwavs
2, That the road allowances shown on this Plan of Subdivision shall be dedicated on the
final plan as a public highway to the appropriate road authority.
3. That the street(s) shall be named to the satisfaction of the Municipality of Kincardine.
4. That any dead ends and/or open sides of road allowances created by this Plan of
Subdivision shall be tenn/nated in 0.3 metre reserves to be conveyed to and hetd, in
trust, by the Municipality of Kincardine until required for future road allowances or the
development of adjacent land.
Parkland/Ooen Soace
5. That the owner conveys land in the amount of 5% of the land included in the Plan to the
Municipality of Kincardine for park purposes pursuant to the Provisions of Section
51(5)(a) of the Planning Act R.S.O. 1990 c.P.13. Alternatively, the Municipality of
Kincardine may accept cash-in-lieu of the said conveyance and under provisions of
Section 51(8) of the Planning Act, R.S.O. 1990 c.P.13 the Municipality of Kincardine is
hereby authorized to do so.
Subdivision Aqreement
6. That the owner enter into an agreement with the Municipality of Kincardine to satisfy all
the requirements, financial and otherwise, of the municipality concerning the provision of
roads, installation of services, facilities and drainage.
.,
48
51f ,2../
7. That the subdivision agreement is registered by the Municipality of Kincardine against
the land to which it applies and a copy of the registered agreement be forwarded to the
County of Bruce prior to final approval of the subdivision plan.
8. That the draft approval for Plan of Subdivision 41T-2007-02.22 in the Municipality of
Kincardine shall lapse on (three years from date of draft approval) unless it has been
extended by the County of Bruce.
Easements
9. That such easements as may be required for utility or drainage pUrposes shall be
granted to the appropriate authority.
Services
10. The applicant agrees to make satisfactory arrangements with Westario Hydro for the
provision of permanent or temporary electrical services to this plan.
12. The applicant agrees to make satisfactory arrangements for the provision of permanent
or temporary telephone services to this plan.
Zonino Bv-Iaw
13. That the County of Bruce be advised by the Municipality of Kincardine that the Plan of
Subdivision conforms with the Zoning By-law approved under the Planning Act.
Sauneen Vallev Conservation Author/Ix
14. That prior to final approval by the County, the owner shall submit for review and approval
of the Saugeen Valley Conservation Authority a stonnwater management plan prepared
by a technically qualified consultant. The plan shall detail the methods that will be used
to control stormwater and erosion and sedimentation within the development lands and
abulling properties dUring and following construction. The report shall also detail the
methods that will reduce any negative impacts to water quality.
15. That prior to final approval by the County, the owner shall submit for review and approval
of the Saugeen Valley Conservation Authority a lot grading plan prepared by a
technically qualified consultant.
16. That the Subdivision Agreement between the owner and the municipality contain the
following provisions with wording acceptable to the SVCA:
a) the owner agrees to carry out or cause to be carried out the works recommended
in the storrnwater management plan and lot grading plan to the satisfaction of the
Saugeen Valley Conservation Authority.
b) the Municipality of Kincardine will assume ownership, operation and maintenance
responsibility for the storm water works, including detention and/or retention
facilities in perpetuity.
. Clearance Conditions
17. That prior to the granting of Final Approval, the County of Bruce is to be advised by the
Municipality of Kincardine that Conditions Nos. 2 to 13 inclusive have been carried out to
their satisfaction. The clearance letter from the Municipality of Kincardine shall include a
brief but complete statement detailing how each condition has been satisfied.
49
//5 6"
"
18. That prior to the granting of Final Approval, the County of Bruce is to be advised by the
Saugeen Valley Conservation Authority that Conditions Nos. 16 to 18 inclusive have
been carried out to their satisfaction. The clearance letter shall include a brief but
complete statement detailing how each condition has been satisfied.
Notes to Draft Approval: Subdivision File No. 41T-2007-02.22
1. It is the Owner's responsibility to fulfill the Conditions of Draft Approval and to ensure that the
required clearance letters are forwarded by the appropriate agencies to,the County of Bruce
Planning and Economic Development Department quoting the appropriate subdivision file
number.
2. Inauguration, or extension of a water works or sewage works Is subject to the approval of the
Ministry of the Environment under Se,ction 52 and Section 53 of the Onterio Water Resources
Act, R.S.O. 1990.
3. We suggest that you make yourself aware of section 144 of the Land Titles Act and subsection
78(10) of the Registry Act.
Subsection 144(1) of the Land Titles Act requires that a Plan of Subdivision of land that is located
In a land titles division be registered under the Land Titles Act. Exceptions to this provision are
set out in subsection 144(2).
Subsection 78(10) of the Registry Act requires that a Plan of Subdivision of land that is located
only in a registry division cannot be registered under the Registry Act unless that title of the
Owner of the land has been certified under the Certification of Title Act.
Exceptions to this provision are set out in clauses (b) and (c) of subsection 78(10).
4. Clearances are required from the following agencies:
Municipality of Kincardine
1475 Concession #5
RR#5
Kincardine, ON. N2Z 2X6
Saugeen Valley Conservation Authority
R.R. #1
Hanover, ON.
N4N 368
Ministry of Culture
Southwest Anchaeological Office
gOO Highbury Avenue
London, ON.
N5Y 1A4
5. Note that you will not be advised in writing of the lapsing date of the Draft Plan Approval. It is your
responsibility to provide the approval body with the required infonmation and fees to extend this
draft approval. Should the infonmation and fees not be received prior to the lapsing date, the Draft
Plan Approval will lapse. There is no authority to revise the approval after the lapsing date. A new
subdivision application under Section 51 of the Planning Act will be required.
Please note that an updated review of the plan and revision to the Conditions of Approval may be
necessary if an extension is to be granted,
6_ Draft Approval may be reviewed by the County of Bruce from time to time to determine whether
draft approval should be maintained or conditions amended andlor added.
7, The Owner is advised that Draft Approval is not a commitment by the MunIcipality of Kincardine
to water or sanitary servicing capacity. To secure this commitment the Owner must contect the
Municipality of Kincardine directly.
8. Final Plans - When the survey has been completed and final plan prepared, to satisfy the
requirements of the Registry Act, they should be forwarded to the County of Bruce. If the plans
comply with the terms of approval, and we have received the required agency clearances, the
County's stamp of approvai will be endorsed on the plan and it will be forwarded to the Registry
Office for registration.
The following is required for registration under the Registry Act:
One (1)
Five (5)
original mylar
white paper prints (10 include 1 print for OLS)
'I ·
57
50
SCHEDULE "M" OF AGREEMENT
NOTE: It is understood and agreed that this Schedule forms part of the Municipality's
Agreement.
SPECIAL PROVISIONS
1. Phased Registration
This Agreement is for Lots 1-37 and associated blocks, Draft Plan 41T-207.02.22. A
subsequent Agreement will be required for the balance of the lots.
2. Parkland Dedication
The Developer and the Municipality agree that the parkland dedication will be satisfied
within the Agreement and upon registration of the balance of the subdivision.
3. Saugeen Valley Conservation Authority
a) The Developer agrees to complete any works required by its "Stormwater Management
Report", "Lot Grading Plan" and "Erosion Sedimentation Control Plan" in accordance
with approved plans by the Saugeen Valley Conservation Authority.
b) The Developer agrees to notify the Saugeen Valley Conservation Authority at least 48
hours prior to the initiation of anyon-site development.
4. Servicing Prior to Registration
a) Notwithstanding Clause 2.3 (a) of the Agreement, the Developer may, subject to written
authorization from the Municipality, at his own risk, start construction prior to
registration of the plan provided the Municipality has been satisfied that:
i) Securities for the work have been received.
ii) Liability insurance has been received.
iii) Municipal, Ministry of Environment and Saugeen Valley Conservation Authority
approvals of the design drawings have been received.
iv) The draft of the registered plan has been approved by the Municipality.
b) If the Developerreceives authority to proceed under Section 4 (a) above, it acknowledges
and agrees that such servicing work is done at its sole risk and the Developer agrees to
indenmify and save harmless the Municipality with respect to any claim, demand, action,
cost, suit or loss by anyone whomsoever which may occur as a result of the registration of
a plan of subdivision.
5. Road Construction and Restoration
The Developer will be reconstructing a portion of Penetangore Row to lower the grade
for drainage purposes. All costs associated with modifications to the storm sewer, road
reconstruction and paving, curb replacement, sidewalk replacement, if warranted, and
restoration of boulevards and driveways, will be borne by the Developer.
As the Developer will be cutting into the asphalt in other areas on Penetangore Rowand
Saratoga to install municipal services, the Municipality and the Developer have agreed
that the Developer will remove all of the asphalt and provide a base course of asphalt to
municipal standards along the fulllengtb of disturbance of those two roads. The
Municipality has agreed that they will, as part of their annual paving program, provide the
surface course of asphalt on these roads so as to avoid the disruption of the many patches
that would be required.
'( 'r. ...
00
51
6. Servicing Drawings
The following is a list of servicing drawings that have been reviewed or are currently
under review by the Municipality, for this development.
Drawing No. Rev. Description Revision Date
No.
SPl 1 Site Plan Sept. 10,2007
Cl 1 200 Lane Sent. 10, 2007
C2 1 Penetangore Row Sept. 10, 2007
C3 1 Penetangore Row Sept. 10, 2007
C4 1 Saratoga Road Sent. 10, 2007
C5 1 Saratoga Road Sept. 10, 2007
C6 1 Lot Grading Plan Sept. 10, 2007
C7 1 Miscellaneous Details and Sept. 10, 2007
Tvoical Cross-Sections
C8 1 Phase II Servicing (Preliminary) Sept. 10, 2007
C9 1 Miscellaneous Details Sent. 10, 2007
ClO 1 Phase II Servicing (Preliminary) Sept. 10, 2007
El 0 Electrical Servicing Layout Not complete